Contract Practice - NEC & JCT Flashcards

1
Q

What is delay damages?

A
  • It is a genuine pre-estimate of loss suffered by the employer because of late completion of the works. This is included into the contract.
  • They are not a penalty; they need to be a genuine estimation as if the courts decide are unreasonable, they might not be enforceable.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
2
Q

How do you apply delay damages?

A

• Contractor/subcontractor pays delay damages at the rate stated in the contract data from the completion date until actual completion or the date on which the employer takes over the works

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
3
Q

What clause is delay damages in NEC?

A

• X7

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
4
Q

How was the time entitlement assessed in implemented compensation events?

A

• You assess the compensation event in accordance with the accepted programme

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
5
Q

How are delay damages calculated by the client?

A
  • Loss of rent or other income
  • Additional professional fees
  • Legal costs
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
6
Q

What is included in subcontract part 1 and part 2?

A

• Contains information that is specific to the project
Part 1
• NEC option used
• Works information
• Boundaries of the site
• Starting and access dates
• Risk and insurances
• Defect period

Part 2
• Key people
• Direct fee percentage
• Working fee percentage
• Design overhead fees

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
7
Q

What is the difference between part 1 and part 2?

A

• Part 1 completed by the employers and part 2 completed by the contractor

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
8
Q

How did you ensure liabilities documents are up to date?

A

• For example, employer and public liability was expiring and therefore I requested it from the supply chain

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
9
Q

What is disallowed cost?

A
  • On my project the main point of disallowed cost is:
  • It’s a cost that is decided by the employer that is not justified by the contractor’s accounts and records
  • Was incurred in relation to work on services that are not part of the works information
  • Subcontractor have not given an early warning which this subcontract required him to give
  • Cost of correcting defects
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
10
Q

What is defined cost?

A
  • The amount payment paid a contractor has paid a sub-subcontractor minutes retention correction of defects etc.,
  • Cost of subcontractor’s people priced at the agreed subcontract rates.
  • Cost of invoices for equipment
  • Less Disallowed cost
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
11
Q

What is a JCT contract?

A

• Joint contracts Tribunal

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
12
Q

Key characteristics to choose a contract?

A
  • Size, value, complexity
  • Need for contractor design
  • Certainty on final cost
  • Appetite for risk and risk transfer
  • Employer experience
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
13
Q

What are some of the contracts in the JCT family?

A
  • Design and build contract
  • Standard Building contract
  • Management Building contract
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
14
Q

When would you use a standard building JCT contract?

A
  • Traditional procurement route
  • When the design is complete and
  • Greatest price certainty
  • Might take a bit longer
  • Lump sum with interim payments
  • Most likely for large or complex construction project
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
15
Q

When would you use a design and build contract?

A
  • When the client wants the contractor to design and construct the works
  • Contractor completes the design based on concept provided through the employers advisers or will be responsible for producing and completing the design right from the outset
  • The employer normally uses an agent to administer the contract
  • Client wishes to minimize the risk as the client wil have no responsibility for design
  • Where the employer does not want to retain full control over the design development
  • Lump sum
  • The contractor needs to be experienced as the contractor assumes more risks and responsibilities under other JCT contracts
  • In the event between Employer requirements and contractor proposals, the contractor proposal is to prevail.
  • Employer is responsible for issuing statements or instructions as required under the contract
  • Advantage – single point of contract, early start on-site , early price certainty
  • Disadvantages – Reduced quality , client needs to commit to an concept design early
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
16
Q

When would you use a management contract?

A
  • A management contractor is appointed by the client for a fee
  • Suitable for large complex project
  • Employer is responsible for the design and this is usually supplied to the management contractor by the architect or design team working on the employer’s behalf.
  • The employer is responsible for the design dn this is usually supplied to the management contractor by the architect or design team working on the employers behalf
  • Management contractor appoints works contractors. Contractor has a direct contractual link with all the works contractors and is responsible for all the construction works.
  • Advantage – early start on site, design overlap between design and construction , the contractor contributes to the design, work packages are awarded competitively
  • Disadvantage – must have a good quality brief to design team , cost certainty is not achieved until all the trade packages are awarded,
  • Management contractor should be appointed early so they can cooperate with the architect and contract administrator
  • Prime cost (actual cost) plus management fee
  • Interim payments are monthly
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
17
Q

What is a relevant matter and name an example?

A

• It is a matter for which the client is responsible for affecting the progress of the works
• The contractor can claim direct loss and expense
Example
o Failure to give the contractor possession or access of the site
o Delays in receiving instructions
o Disruption caused by works being carried out by the client.
o Failure to provide materials

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
18
Q

What is a relevant event and name an example?

A
  • Event that causes a delay to the completion date, which is caused by the client, or a neutral event not caused by either party
  • Contractor can claim extension of time which helps shielding you from getting delay damages
    • Variations
    • Exceptionally adverse weather
    • Delay in giving the contractor possession of the site
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
19
Q

Example of an event being both a relevant matter and a relevant event?

A
  • Materials not being supplied to the contractor which caused a delay to the programme which caused an expense to the contractor.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
20
Q

What does NEC stand for?

A
  • New engineering contract
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
21
Q

What does ECC stand for?

A
  • Engineering and construction contract
22
Q

What are some perceived advantages of using the NEC ECC contract?

A
  • Plain English
  • Mutual trust and cooperation
  • Proactive risk management through the EW mechanisms
  • Encourages all parties to resolve cost and programme issues up front
23
Q

What are the 6 main options?

A
  • Option A: Priced contract with activity schedule.
  • Option B: Priced contract with bill of quantities.
  • Option C: Target contract with activity schedule.
  • Option D: Target contract with bill of quantities.
  • Option E: Cost reimbursable contract.
  • Option F: Management contract.
24
Q

What is an option A?

A
  • Priced contract with an activity schedule
  • Risk of carrying it largely borne by the contractor
25
Q

What is an option B?

A
  • Priced contract with bill of quantities where the risk of carrying out the works at the agreed prices being borne by the contractor.
  • Option B is measurable
26
Q

What is option C?

A
  • Target cost contract with an activity schedule
  • Pain gain mechanism
  • Paid through defined cost plus fee.
27
Q

What is an option D?

A
  • Target cot contract with bill of quantities
  • Share pain mechanism
  • Target moves with compensation events
28
Q

What is an option E?

A
  • Cost reimbursable contractor
  • Financial risk with employer
  • Contractor reimbursed for all actual cost plus an agreed fee
29
Q

What is an option F?

A
  • Option F is a cost-reimbursable management contract
  • Works are designed or constructed by multiple subcontractors who are contracted to a management contractor.
30
Q

Risk profiles of different options?

A
31
Q

Key differences between NEC and JCT construction contracts?

A
  • NEC is drafted in plain English and avoids using legal terms
  • NEC has early warning process
  • JCT splits up the components of time and cost dealing with the independently. NEC treats them together
  • JCT its variations, NEC : compensation event
  • Person that acts in charge of the employer: JCT contract administrator , NEC project manager.
  • QS is not mentioned in NEC, only PM
  • NEC is considered a more collaborative approach to working
  • NEC programme is a contract document that CEs are based on
  • NEC has periods of replies
  • JCT contains provisional sums , NEC does not
32
Q

When is JCT is used:

A

The JCT form of contract is typically better suited in situations where the employer wants more control over project delivery. The commercial development community generally utilize the JCT form of contract since it provides a comprehensive balance of risk between Employer and Contractor.

33
Q

When is NEC is used?

A
  • the public sector and is used by most national and local government bodies and agencies following the UK Cabinet’s Office endorsement in 2008.
  • NEC provide more of a collaborative approach to contracting but does hold a higher level of risk in terms of its administration.
  • major infrastructure and building contracts that are over £5m, while JCT is better suited for projects between £5 million and £25 million.
34
Q

Secondary options under NEC3?

A

Dispute resolution

WI

W2

X Clauses

Option X1: Price adjustment for inflation (Used only with option A,B,C & D) –

Option X2: Changes in the law

Option X3: Multiple currencies (used only with options A & B)

Option X4: Ultimate holding company guarantee

Option X5: Sectional completion

Option X6: Bonus for early completion

Option X7: Delay damages

Option X8 to X11: Not used in NEC

Option X12: Partnering

Option X13: Performance bond

Option X14: Advanced payment to the contractor

Option X15: The contractor’s design

Option X16: Retention (not used with option F)

Option X17: Low performance damages

Option X18: Limitation of liability

Option X20: Key performance indicators (not used with option X12).

Additional conditions

  • Z clauses
35
Q

What are Z clauses?

A

Z clauses are used to amend standard form NEC contracts. They can be inserted into NEC contracts as a means of adding conditions or amending wording.

Problems might arise if they are used inappropriately as they might conflict with other clauses in the contract.

36
Q

What are different types of float on a NEC programme?

A
  • Total float
  • Time risk allowance
  • Terminal float
37
Q

What is Total float and who is it owned by?

A
  • Time an activity can be delayed from its early start date without delaying planned completion
  • available either to the Employer or the Contractor (on a first come first served basis) to mitigate delays caused by compensation events or slow progress, i.e. its is ‘owned’ by the project;
38
Q

What is time risk allowance and who is it owned by?

A
  • Duration allowed in an activity to account for the risk of not completing that activity in the minimum possible period.
  • It is ‘owned’ by the Contractor and cannot be used to mitigate the effect of a compensation event;
39
Q

What is terminal float and who is it owned by?

A
  • Difference between planned completion vs completion date.
  • This is also ‘owned’ by the Contractor and cannot be used to mitigate the effect of a compensation event.
40
Q

How can the planned completion be changed?

A
  • Anything can change it
41
Q

How can completion date change?

A
  • Compensation event
42
Q

What is the Works Information?

A
  • It specifies and describes the works the contractor is to provide and how are they to get carried out.
43
Q

What is a compensation event and name an example?

A
  • An event that can change the cost of the work or the time needed to complete it or both. If there is an acceptance from the Employer, the contractor will possibly be entitled to more money or time.
  • Example – PM issues an instruction changing the Works information, PM might not allow access, or tell contractor to stop or start work.
44
Q

What are EW notices?

A
  • Mechanism for both parties to inform each other of an event that can affect the works such as increasing the cost of the works or causing delays in completion or meeting a key date and impairing the performance of the works.
  • Clause 16.1
  • If the party does not raise an EW within 8 weeks of becoming aware of it, they are not entitled to a compensation event.
45
Q

What other roles does the contract administrator have?

A
  • Review Contract instructions alongside the contract before their issued
  • Site inspection

Adjust the constract sum and the final account

46
Q

Why is it important administer the contract fairly and effectively under the conditions of the contract?

A
  • Reduce disputes
  • Breach of contract
47
Q

Why is it important keep accurate records of the administration from the inception of the project to completion?

A
  • Audit trail.
  • Records can prevent disputes from occurring.
  • Demonstrate work done and cost to date to the employer.
  • Quality control.
48
Q

What is FIDIC?

A
  • FIDIC is International Federation of Consulting Engineers, known by its French acronym.
  • Widely used international
  • They require amendment to be used in the UK construction industry to comply with UK legislation
  • (Other type of contract is ICHEME)
49
Q

Do you know an example of the FIDIC contract?

A
  • The red book, yellow, silver, green
  • Red book - Suitable for where design responsibility design lies with the employer and the contractor carries out in accordance with the employers’ design
  • Payment made through bill of quantities however there is an option for lump sum
  • Work is measured
50
Q

What did you understand from appropriate contract selection?

A

Understood that based on the client’s attitude on risk you can choose different contracts.

51
Q

When assessing compensation events do you forecast defined cost or use actual cost?

A

there is a diving date which to the date that CE was notified. Prior to the date you account for actuals and after the date forecast+ the resulting fee.

Clause 63.1

52
Q

How do you issue contractual correspondence, is there a prescribed way within your contract?

A
  • period of reply 2 weeks for contractor, 1 week for subcontractor