Domain 7 - Construction Flashcards

1
Q

Differentiate between construction contract administration and contractor project management

A

*Construction Contract Administration. Activities related to administering the contract for construction, often performed by the architect/engineer.
*Contractor Project Management. Activities related to managing the construction process, typically performed by the contractor.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
2
Q

Identify the responsibilities of the contractor according to AIA A201 and EJCDC-700

A

*Execute the work.
* Control the Project Schedule
* Monitoring subcontractor and supplier performance
*Payment Procedures
*Jobsite Safety
*Quality Assurance and Quality Control
*Familiarity with the site and local conditions
*Study and comparing the various portions of the contract documents.
*Reporting nonconformity of the contract documents with current laws, codes, statues, ordinances, rules, regulations, or lawful orders
*Provide labor, materials, equipment, tools, construction equipment, and machinery.
* Supervising and directing work
* Being solely responsible for and in control of construction means, methods, techniques, sequences, procedures, and coordination.
*Inspect installed work in anticipation of subsequent work.
* Making substitutions with permissions from owner/AE
*Enforcing discipline, and good order on the site.
*Warranting that material and equipment will conform to contract documents.
*Paying taxes
*Securing Building Permit and other permits, fees, licenses, and inspections by governing agencies.
*Employ a competent superintendent
*Prepare a construction schedule for the work
*Prepare a submittal schedule/submittals for approval.
*Maintain a set of contract documents and copy of submittals at the site that are marked to indicate field changes and selection made during construction.
*Keeping the site free from accumulation of waste materials or rubbish.
*Permitting owner and architect access to the site.
*Scheduling inspections with AHJ
*Submitting record drawings, operation and maintenance manuals, and other project data to owner or authorized recipients.
*Promptly Pay subcontractors and suppliers.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
3
Q

Describe three types of graphic schedules used for construction

A

1.) Gantt Chart
2.) Critical Path Method
3.) LBS schedule

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
4
Q

Uses algorithms to establish various types of relationships
between activities and the dates when they start and stop
to establish the sequence of activities that constitutes the
shortest path through all the activities.
1.) Gantt Chart
2.) Critical Path Method
3.) LBS schedule

A

2.) Critical Path Method

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
5
Q

Based on tracking the continuity of crews as they move
from one production task to the next, and emphasizes
physical locations to plan, analyze, and control workflow.
Uses graphical flowline diagrams that show the movement
of crews through locations of work tasks.
1.) Gantt Chart
2.) Critical Path Method
3.) LBS schedule

A

3.) LBS schedule

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
6
Q

A type of bar chart that lists sequential activities or tasks
vertically and is considered the simplest form of a schedule.
1.) Gantt Chart
2.) Critical Path Method
3.) LBS schedule

A

1.) Gantt Chart

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
7
Q

The process of overlapping activities to permit portions of construction to start prior to completion of the overall design and construction documents.

A

Fast-track scheduling

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
8
Q

Describe how the fast-track scheduling technique could affect the
design team

A

The architect/engineer may be simultaneously involved in design, construction documents, development of multiple bid or proposal packages, procurement, and construction contract administration.
It adds to the responsibilities of the architect/engineer, and a larger portion of construction documents preparation time is required as compared to an identical project using a more traditional method. Increases the cost for the architects services.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
9
Q

Performing one portion of the work prior to another portion in either a logical order or a predetermined order.

A

Sequencing

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
10
Q

Which of the following entities is responsible for sequencing the construction work?
a.) Owner
b.) Architect/engineer
c.) Contractor
d.) None of the above

A

c.) Contractor

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
11
Q

Identify the activities associated with Field Engineering.

A
  • Site surveying
  • Determining facility placement
  • Developing the layout from the contract drawings
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
12
Q

Quality control requirements for construction items in the specifications, or references to various industry or trade association standards related to product or equipment to establish minimum acceptable conditions.

A

Tolerances

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
13
Q

*Regular cleaning as determined by the contract documents
which reduces accidents and makes access to work areas
easier for all workers.

A

Progress cleaning

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
14
Q

*Cleaning that is performed immediately prior to turning
the project over to the owner at substantial completion.

A

Final Cleaning

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
15
Q

List Personal Protective Equipment (PPE) used on the jobsite.

A

Hard hats, Ear Protection, Dust Masks and respirators, Safety glasses, goggles, and face shields, safety vests, Safety harnesses, lanyards, and lifelines, gloves, and boots (steel toe)

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
16
Q

These meetings address the progress and scheduling
of the work, coordination between the contractor and
subcontractors, and coordination between two or more
subcontractors. These meetings frequently address contract
issues such as applications for payment, project site safety,
requests for information, and contract modifications. The
owner and architect/ engineer typically do not attend these
meetings.
a.) Progress Meeting
b.) Contractor/Subcontractor Meeting
c.) Preinstallation Meeting
d.) Closeout Meeting
e.) Meeting with Client/Project Closeout

A

b.) Contractor/Subcontractor Meeting

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
17
Q

These meetings are conducted near the finish of the
project to review the procedures and activities necessary to
complete the project.
a.) Progress Meeting
b.) Contractor/Subcontractor Meeting
c.) Preinstallation Meeting
d.) Closeout Meeting
e.) Meeting with Client/Project Closeout

A

d.) Closeout Meeting

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
18
Q

These meetings concern how the work is developing and
could include the owner, architect/engineer, contractor,
construction manager, and others invited for specific
purposes. They provide a forum in which matters pertinent to
the timely completion of the work can be discussed.

a.) Progress Meeting
b.) Contractor/Subcontractor Meeting
c.) Preinstallation Meeting
d.) Closeout Meeting
e.) Meeting with Client/Project Closeout

A

a.) Progress Meeting

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
19
Q

This meeting is to discuss what will occur during project
closeout. This meeting provides the opportunity to mitigate
risk by obtaining feedback from the client on the architect/
engineer’s performance.

a.) Progress Meeting
b.) Contractor/Subcontractor Meeting
c.) Preinstallation Meeting
d.) Closeout Meeting
e.) Meeting with Client/Project Closeout

A

e.) Meeting with Client/Project Closeout

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
20
Q

These meetings help to clarify installation procedures,
phasing, and coordination of the participants and processes
involved in the installation of a specific material, product,
system, or equipment.

a.) Progress Meeting
b.) Contractor/Subcontractor Meeting
c.) Preinstallation Meeting
d.) Closeout Meeting
e.) Meeting with Client/Project Closeout

A

c.) Preinstallation Meeting

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
21
Q

Describe the purpose of Submittals.

A

*NOT a Contract document because A/E did not author or prepared.
*Submittals expand on the information indicated on the contract documents.
* AIA A201, P 3.12.4: The purpose of is to demonstrate how the contractor proposes to conform to the information given and the design concept expressed in the contract documents.
*Part of Quality assurance
*Provide the owner with information on the products, materials, systems, and equipment incorporated in the project.
* Administrative and Procedural requirements found in General Conditions/Div. 01-General Requirements (Submittal specification section), and in individual specifications sections in Div 02-49.)

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
22
Q

Describe the purpose of a submittal schedule

A

A submittal schedule assists the architect/engineer and the contractor in maintaining an even pace for submittals preparation, submission, and review. A properly prepared submittal schedule
aids the contractor to include all critical submittal items and helps the preparation and review activities by controlling the flow of submittals.
* contractor is required to submit a schedule at the beginning of a project by AIA 201, and EJCDC C-700

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
23
Q

Differentiate between action and informational submittals

A

*Action submittals are submittals requiring responsive action by the architect/engineer.
*Informational submittals are submittals not requiring responsive action by the architect/engineer.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
24
Q

Describe the 3 types of action/informational submittals listed in SectionFormat.

A

*Product data – Includes the manufacturer’s technical information, illustrations, schedules, diagrams, performance charts, instructions, and brochures that illustrate physical appearance, size, and other characteristics of materials and equipment.
*Shop drawings – Shop drawings are drawings, diagrams, illustrations, and schedules that specifically illustrate and depict some portion of the work in more detail.
*Samples – Physical objects that show color, texture, and other appearance characteristics
of actual products and materials.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
25
Q

Name other types of action/informational submittals that may
be required by the contract documents

A

Certificates, Delegated Design Submittals, Test and Evaluation Reports, Manufacture’s instructions, Source QC submittals, Site QC Submittals, Coordinating drawings, Manufacturer Reports, Sustainable Design Submittals, Special Procedure Submittals, and Qualification statements

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
26
Q

Submittals that are submitted during project closeout that do not require responsive action by the architect/engineer but may require architect/engineer review.

A

Closeout submittals

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
27
Q

Describe the types of Closeout Submittals.

A
  • Maintenance agreements
  • Operation and maintenance data
  • Bonds
  • Warranty documentation
  • Record documentation
  • Sustainable design closeout documentation
  • Software
  • Keying
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
28
Q

Describe the purpose of Maintenance Materials Submittals

A

These submittals are for materials that are specified to be furnished to the owner for maintenance purposes. Maintenance materials submittals are sometimes known as “attic stock.”
Examples include spare parts, extra stock materials, and tools.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
29
Q

Describe the preparation, review, and processing of
submittals.

A

Submittals are usually prepared and assembled by manufacturers, suppliers, fabricators, and subcontractors for the contractor’s review and approval prior to submission to the architect/
engineer. Submittals are initially reviewed and approved by the contractor to ensure that contract document requirements have been met, to check dimensions, and to coordinate with
subcontractors. Once approved by the contractor, they are submitted to the architect/engineer for review and processing. The architect/engineer’s review is limited to determining whether the
submittal is consistent with the design intent indicated in the contract documents. Submittals should be complete and accurate, in conformance with specified requirements, and consistent with project conditions. They should be prepared, submitted, and reviewed in a timely manner according to the approved submittal schedule and the current construction progress schedule. Only submittals that are specified to be submitted should be processed. Submittals not required by the contract documents are usually returned without review by the architect/engineer

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
30
Q

Some building components have unique design requirements with which only the product manufacturer would be familiar, or the manufacturer has the capacity to design and engineer the attachments of the components to the facility. For these situation, the A/E specifies that the design and engineering is delegated to the contractor as part of submittals.

A

Delegated design and engineering

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
31
Q

Distinguish between Observe and Inspect

A

To observe implies a less focused view of what is being looked at, that simply noticing or seeing is enough.
To inspects, it implies a more careful observation designed to critically evaluate what is in place.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
32
Q

Describe the purpose of the architect/engineer’s
site visits.

A
  • Ascertain the progress and quality of the work.
  • Inform the owner of known deviations from the contract
    documents and defects and deficiencies observed in the work.
  • Keep the owner informed of the progress of the work.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
33
Q

Describe the purpose of the Contractor’s site visits.

A

*Observe conditions at the site affecting the work and
correlate them with a review of the contract documents and
report any observed errors, omissions, and inconsistencies
to the architect/engineer.
*Prepare and submit a comprehensive list (initial punch list)
of items to be completed or corrected prior to final payment
* Inspect each portion of the work prior to performing subsequent work.
* Inspect work performed by the owner or seperate contractor if the contractor’s work depends on that work.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
34
Q

Describe the purpose of the Product Representative’s site visits.

A

*Complete inspections required for products subject
to a warranty.
*Verification of conformance with manufacturer’s instructions.
*The provision of training for the workers.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
35
Q

Describe the purpose of the Facility Manager’s site visits.

A

*Become familiar with the location of concealed items,
such as piping, conduit, cabling, and structural connections
*Become familiar with the means and methods employed by the contractor.
*Observe construction of the facility for which the facility manager will be responsible.
*Participate in the decision-making regarding contract modifications.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
36
Q

Describe the purpose of the AHJ’s site visits.

A

Verify that code and ordinance requirements have
been met by performing building, mechanical, electrical, elevator, fire, life safety, health, zoning, accessibility, and critical structural inspections of the Work.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
37
Q

Describe the purpose of the Owner’s site visits.

A

Owner has NO contractual responsibilities for site visits under the standardized General Conditions. However if he does site visits, then clear lines of responsibly and communication need to be established to avoid erroneous presumptions.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
38
Q

Describe the purpose of the Lender’s site visits. (usually a third party)

A

*to keep the lending institution advised of the progress and quality of the construction work.
*to ensure the work completed and the application for payment are consistent.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
39
Q

Identify the conditions in which work will be considered defective or nonconforming.

A

Standardized general conditions stipulate that work is considered defective or nonconforming under the following conditions:
* Neither new nor of good quality
* Not free from defects
* Not conforming to the contract documents

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
40
Q

True or False?
The architect/engineer has the authority to accept nonconforming work.

A

False (only the Owner can accept non conforming work.)

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
41
Q

Describe the two situations where concealed conditions may
be uncovered to examine the concealed work.

A

*If work is concealed contrary to the written request of the architect/engineer or the contract documents, the architect/engineer has the right to request that the work be uncovered and replaced at the contractor’s expense.

*If the architect/engineer has not specifically requested to examine the work before it was covered, and if the uncovered work is defective or nonconforming, the contractor is obligated to
correct the work and the reinstallation of the covering work may be at the contractor’s expense. If the work is determined to be conforming, then the cost becomes the owner’s responsibility.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
42
Q
  1. Which of the following statements is true regarding stopping the work on a project? Check all that apply.

a.) The owner has the authority to order the contractor to stop work if the contractor fails to correct work that is not compliant
with the contract documents
b.) The architect/engineer has authority to order the contractor to stop work.
c.) The contractor does not have the authority to stop work, even if the owner has failed to pay the contractor within the time
stipulated in the contract documents.
d.) The contractor has the right to stop work if hazardous materials are encountered during the work that are not addressed in the contract documents.
e.) The owner has the authority to order the contractor to stop work if the contractor repeatedly fails to carry out the work in
accordance with the contract documents.

A

a.), c.), d.), e.)

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
43
Q

True or False?
The owner may suspend the work for any reason.

A

True

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
44
Q

True or False?
If the owner suspends the work, the owner is not obligated to cover
the contractor’s cost associated with the suspension.

A

False

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
45
Q

Which of the following statements are valid reasons for the owner to terminate the work for cause? Check all that apply.
a.) Contractor fails to make prompt payments to workers,
subcontractors, and material suppliers
b.) Contractor disregards laws or other legal requirements
c.) Contractor fails to submit certifications for payment
d.) Contractor is guilty of a material/substantial breach/violation of the contract documents

A

a.), b.), d.)

46
Q

Which of the following statements are valid reasons for the contractor to terminate the work for cause? Check all that apply.
a.) Owner fails to pay contractor
b.) Architect/engineer fails to perform
site visits
c.) Owner suspends the work for a specified
period of time
d.) Owner fails to pay subcontractors

A

a.), c.)

47
Q

Define Quality Assurance as it relates to the construction phase

A

*Quality Assurance - Refers to the procedures for guarding against construction defects and deviations from the contract documents before and during the execution of the work.
It includes submittals, certifications, and other actions to ensure that the proposed products and services meet the contract requirements. (before and during activity)

48
Q

Define Quality Control as it relates to the construction phase

A

*Quality control - Refers to the procedures for evaluating completed activities and elements of the work for conformance with contract requirements. Procedures include testing and inspection of installed work. (completed items)

49
Q

Describe how a quality control process can be a quality assurance process for subsequent work

A

Quality control for one action may become quality assurance for the next step in a process. In each step of the process, the previous quality control becomes part of the quality assurance for the next step. For example, in a slump test for concrete, the test is quality control for the concrete in the mixer and quality assurance for the same concrete not yet placed in the work.

50
Q

Describe how stakeholders and participants affect quality.

A

*The owner must have realistic goals and a reasonable program, budget, project delivery method, and project schedule.
*The architect/engineer’s ability to develop the owner’s requirements into a documented design is critical to defining the quality and the basis for evaluation (such as tolerances and standards).
*The contractor’s performance and the completed project will be evaluated based on meeting the requirements of the contract documents.

51
Q

There is no substitute for clear, concise, correct, complete, and coordinated contract documents. However, because it is impossible to produce perfect construction documents, there will always
be a need to make modifications to the contract documents.

Which of the following entities is responsible for interpretations, clarifications, and modifications?
a.) Owner
b.) Architect/Engineer
c.) Contractor
d.) None of the above

A

b.) Architect/Engineer

52
Q

Describe the purpose of a Request for Information (RFI)

A

RFIs are usually submitted by the contractor to the architect/engineer in order to ask a question about the contract documents or to seek a clarification.

53
Q

Describe the three methods used to make contract
modifications.

A

*Change Directive
*Change Order
*Minor Change

54
Q

Used in the absence of an agreement between the owner
and the contractor on the terms of a change to the contract
documents, or when the value of a change cannot be
determined until after the work is performed

A

Change Directive

55
Q

A written instruction that accomplishes an addition, deletion,
or revision to the contract documents and an adjustment
to the contract time and/or the contract sum/price. These
are signed by the architect/engineer recommending the
change, the contractor accepting the change, and the
owner authorizing the change.

A

Change Order

56
Q

Written orders issued by the owner or architect/engineer
that modify the contract documents and do not involve
an adjustment of the contract time or contract sum/price

A

Minor Change

57
Q

what is the difference between a Proposal request vs a Change Order request?

A

*A proposal request is issued by the owner or A/E to the contractor to request a proposal or a change.
*A Change Order request is issued by the contractor, either in response to a proposal or a change requested by the contractor, and typically includes any cost or time changes.

58
Q

Describe the three common payment intervals

A

*Periodic progress payments – Payments made at set intervals of time. Monthly payments are common for most projects. Small projects with shorter construction periods or projects
using the fast-track method may have shorter intervals between payments.
*Provisional payments – Provisional payments are predetermined partial amounts of the total contract sum/price tied to the attainment of identifiable milestones.
*Single payment – A single payment is made at the completion of the work and are suitable for projects with very short construction periods or have a small contract sum/price

59
Q

Describe the contract responsibilities of the architect/
engineer when certifying payment applications.

A

*The architect/engineer has observed the work in progress and evaluation of the contractor’s application for payment.
*The architect/engineer acknowledges that the contractor
is entitled to payment.
*The architect/engineer’s certification is based on the knowledge,
information, and belief that the work has progressed to the point
indicated and the work conforms to the requirements of the
contract documents.

60
Q

Describe the three applications of Measurement in determining
payment amounts

A

The three applications of measurement are described as follows.
* Observing the level of completion for each schedule of value item and comparing it to the amount requested by the pay application for that item.
* Predetermined amounts are paid at the attainment of a specified milestone.
* Unit prices applied to the actual installed quantities to determine amount to be paid.

61
Q

Describe the Schedule of Values

A

*An itemization of the costs of the work apportioned across various divisions of work, which together comprise the total contract sum/price for lump sum or stipulated sum contracts.
*It is prepared by the contractor according to the contract documents and typically uses the project manual table of contents as the organizational format. ( Uniformat)
*Used as the basis for submitting and reviewing progress payments

62
Q

Describe the Schedule of Values

A

*An itemization of the costs of the work apportioned across various divisions of work, which together comprise the total contract sum/price for lump sum or stipulated sum contracts.
*It is prepared by the contractor according to the contract documents and typically uses the project manual table of contents as the organizational format. (Uniformat)
*Used as the basis for submitting and reviewing progress payments

63
Q

Components of the Payment process

A

1.) Application forms (AIA G702 Application and Certification for Payment, or EJCDC C-620)
2.) Schedule of values
3.) Contractor’s preparations
4.) A/E review application for payment
5.) A/E certification for payment

64
Q

Describe the purpose of Retainage

A

Retainage is not to force the contractor to perform, but to protect the owner against errors in estimating the value of work completed or defective work, and is used to settle other participant
(third-party) claims against the contractor before the release of final payment.

65
Q

List the reasons that allow the architect/engineer to
withhold payment to the contractor

A

AIA Document A201™ and EJCDC C-700 provide several reasons for the architect/engineer to withhold payment to the contractor.

*Defective work not remedied
*Third party claims filed or expected to be filed
*Failure of contractor to make payments properly to subcontractors
*Repeated failure to carry out the work according to the contract documents

66
Q

Describe the repercussions should the owner fail to make payment to the contractor

A

If there is a failure to make payment within the prescribed times, without cause under the contract conditions, the owner may be in material breach of contract. In this situation, the contractor
is protected under the agreement and the general conditions. Upon prior written notice, the contractor may stop work if payment is not made within the notice period. The owner’s exposure
to liability in such instances may include the contractor’s cost of demobilization and the cost of delay and remobilization after the breach is rectified by the owner. If the breach is not rectified by
the owner and the contract is terminated, the owner may also be liable for damages resulting from the contractor’s loss of profit.

67
Q

Describe the purpose of a Lien

A

A lien is the legal right of a party or claimant, such as a subcontractor, to control the improved property of another or have it sold for payment of a claim. Typically, if a contractor, a subcontractor, a sub-subcontractor, or a material supplier is not paid, they have a right to file a lien against the property where the work was performed.

68
Q

Describe the purpose of liquidated damages and penalty/bonus
provisions in a construction contract

A

*Liquidated damages are a fixed amount for each day in which the work is not completed within the contract time. The liquidated damages amount is to compensate the owner for not having
beneficial use of the project by the stipulated time. Liquidated damages must be reasonable and documentable.
*The owner pays the contractor a bonus if the project is completed earlier than the contract time. Conversely, if the contractor finishes later than the stipulated date, the owner may invoke a penalty.

69
Q

Describe the processing of the final payment

A

Final payment often requires the processing of a final change order to balance previous payments against the final payment and the final contract sum/price.
Final change order items may include:
* Adjustments to unit price item quantities
* Adjustments to stipulated allowances
* Adjustments for liquidated damages or penalty/bonus clauses
* Adjustments for testing reimbursement when the owner employs the testing services and pays for only passing tests
* Adjustments for reimbursement of utilities
* Adjustments for reimbursement of the owner’s expense for additional architect/engineer services

70
Q

Define Claim

A

A claim is an assertion of a right under the contract.
Owner Claim
Contractor Claim

71
Q

Describe what may become of an unresolved Claim.

A

An unresolved claim is a dispute. When any of the participants refuse to accept their contractual responsibilities, disputes occur. However, a claim may become a dispute no matter how responsibly the parties attempt to reach a resolution.

72
Q

Describe who may file a claim and for what reasons

A

Claims can be made by the contractor against the owner, by the owner against the contractor or the architect/engineer, or by a third party.
**Owner claims will basically be based on the following premises (See PDPG Section 8.11.1.2 for some specific examples):
* Contractor has damaged the owner in some way.
* Contractor has not constructed some portion of the work according to the contract documents.
**Contractor claims will basically be based on the following premises (See PDPG Section 8.11.1.1 for some specific examples):
* Owner has damaged the contractor in some way.
* Architect/engineer’s actions, or lack of timely action, has delayed the work.
* Interpretations or modifications that affect the contract sum/price or contract time for completion of construction.
* Errors, omissions, or lack of coordination of the contract documents.
* Weather delays.
Third-party claims can be many. Most are injury or death to persons and property damage.

73
Q

Define Entitlement

A

a right to benefits specified by law or by contract.

74
Q

Describe the two determinations of a contractor’s entitlement to
a claim.

A

*The first determination for a contractor’s entitlement to a claim is whether the contract documents adequately identify the claim as being within the contractor’s contractual obligations. If the work in
question is not found to be reasonably inferred, the contractor is entitled to a contract modification; on the other hand, if the work is reasonably inferred, then entitlement can be denied.
*The second determination of contractor entitlement is the timing of the claim. Standardized general conditions require the contractor to notify either the architect/engineer or the owner before performing extra work.

75
Q

Describe what is required of an owner’s entitlement to a claim

A

To determine owner entitlement, it must be established whether the work in question required of the contractor is reasonably inferred from the contract documents. If the work in question
is reasonably inferred, the owner’s claim may be upheld without a modification of the contract documents. If the work in question cannot be reasonably inferred, the owner’s claim is denied,
and the work in question is either dismissed or submitted as a contract modification.

76
Q

True or False?
On contractor claims for additional cost, the owner should verify
with the architect/engineer that the costs claimed are representative of the total impact of the conditions giving rise to
the claim.

A

False
The A/E verifies with the Contractor

77
Q

True or False?
After evaluating the submitted claim documentation, the
architect/engineer, or person identified to evaluate the claim, presents the findings to the owner and contractor

A

True

78
Q

True or False?
Documentation should be submitted to support a claim

A

True

79
Q

True or False?
The architect/engineer is the only entity that can make decisions
on claims.

A

False
A/E or initial decision maker

80
Q

Describe how disputes can be avoided

A

Disputes are avoided by a mutual understanding of the interests and limitations of each party. The owner holds the contractor accountable for only those cost elements of the project that are
reasonably documented or foreseeable at the time of pricing. The contractor should understand the owner’s need for thorough documentation justifying a claim.

81
Q

Describe the three methods of alternative dispute resolution
(ADR)

A

Dispute Resolution Boards
Mitigation
Arbitration

82
Q

A formal process that involves the services of one or more
neutrals who are empowered to reach an enforceable decision.
Decisions are considered final and conclusive, and they are not
subject to appeal.

A

Arbitration

83
Q

A non-binding process that involves the services of an
independent neutral third party to facilitate discussions and
communications between parties with the goal of reaching an
agreement that resolves the dispute. If a settlement is achieved,
the parties mutually determine the terms of the settlement and
the agreements are enforceable in court.

A

Mitigation

84
Q

These are selected by the parties and are composed of
individuals with construction knowledge, whose goal is to work
to resolve disputes quickly, fairly, and professionally, in order not
to delay construction.

A

Dispute Resolution Boards

85
Q

Describe the purpose of Project Closeout

A

Project closeout provides an orderly transfer of the completed project from the contractor to the owner

86
Q

Recognize the activities involved with project closeout

A
  • A meeting is held to establish the procedural activities for closeout
  • Commissioning activities are underway or completed
  • Systems and equipment are started and set into operation
  • Demonstrations and training activities take place
  • Closeout submittals are provided to the architect/engineer for review and then delivered to the owner
  • Closeout submittals, A/E reviewed, Owner provided
  • AHJ finish inspections, Issue Certificate of Occupancy
  • Operations and maintenance data are compiled
  • Record documents are assembled
  • The contractor inspects the project and prepares a comprehensive list of items to be completed or corrected (initial punch list)
  • Contractor submits request for Substantial Completion
  • Architect inspects project to verify S.C. and punch list items completion
  • The architect/engineer prepares the Certificate of Substantial Completion
    *The correction period is established, and warranties are collected.
  • Final completion procedures are determined
  • The architect/engineer processes the final application for payment
  • The owner make final payment
  • Post construction services are established, and warranties are collected.
87
Q

Describe the purpose of a closeout meeting

A

A closeout meeting should be conducted prior to beginning closeout activities to review closeout procedures and activities.

88
Q

Recognize the typical topics covered at a project closeout meeting

A
  • Organizational framework for the transition of the project from the contractor to the owner
  • Procedures for determination of substantial completion and final completion
  • Remaining activities on the construction schedule
  • Transition from the contractor to the owner concerning security, routine maintenance, utilities, damage to the work, insurance, and liability for the facility and it’s adjacent grounds.
  • Procedures for commissioning activities, completion, and submittal of records.
  • Procedures for starting of systems and equipment
  • Requirements by AHJ
  • Establishing a schedule for preparing the punch list
    *Procedures for Record Documents
    *Procedures for submitting extended warranties
    *Procedures for demonstrations and training
  • Procedures for submitting operations and maintenance manuals
  • Requirements for the delivery of tools, spare parts, extra materials, and similar items
    *Procedures for removing temporary facilities, tools, equipment from the site
  • Procedures for final cleaning, touch up, and pest control
  • Procedure for changeover to permanent locks and delivery of keys.
89
Q

Who should attend a Closeout meeting?

A

Owner, Owner’s advisors, Facilities Manager
Architect, Engineer, A/E Consultants
Sustainability Consultants, Commissioning Authority
Contractor, Major Subcontractors

90
Q

List the types of Closeouts submittals.

A

1.) Operation and Maintenance Data
2.) Project Record Data
3.) Demonstration and Training
4.) Spare Parts, Extra stock materials and Tools

91
Q

A manual consisting of equipment instructions; materials and finishes information; component diagrams and parts lists; recommended cleaning, maintenance, and replacement schedule; service contracts; and warranty service information.

A

Operation and Maintenance Data

92
Q

Drawings and other documents, including the BIM model, that document the work so it can be utilized by the owner for facility management purposes and future projects.

A

Project Record Data

93
Q

Qualifications for instructors, performance records of attendees,
and videos of instructions for owner’s use in instructing future staff.

A

Demonstration and Training

94
Q

Materials that assist the facility manager in maintaining and operating the facility during the first years of operation

A

Spare Parts, Extra stock materials and Tools

95
Q

The initial operation of permanent systems and equipment, such as the mechanical systems, electrical systems, and elevators

A

Start up

96
Q

when the project, or a portion of the project, is sufficiently complete to permit the owner to use it for its intended purpose

A

Substantial completion

97
Q

Describe the process to determine the date of substantial completion.

A

The date of substantial completion is established by the architect/engineer. When the contractor believes the work is substantially complete, the contractor prepares a list of incomplete work, known as a punch list, and notifies the architect/engineer and owner that the contractor believes the project is eligible for substantial completion. The architect/engineer will inspect the work and review the contractor’s punch list and may supplement the list. If the architect/engineer agrees that the project is eligible for substantial completion, the architect/engineer will prepare the
certificate of substantial completion. If the architect/engineer does not agree that the project is eligible for substantial completion, the architect/engineer will notify the contractor and owner of the reasons for withholding the date of substantial completion.

98
Q

When the work is believed to be substantially complete, which of the following entities is responsible for preparing the punch list?
a.) Architect/engineer
b.) Owner
c.) Contractor
d.) Subcontractor
e.) None of the above

A

c.) Contractor

99
Q

One-year correction Period

A

The one-year correction period is for correcting work that proves to be defective or deficient. It begins on the date of substantial completion

100
Q

Contractor’s warranty

A

The contractor’s warranty stipulates that the materials and equipment that are furnished will be new and of a particular quality that will perform as intended by the design.

101
Q

Differentiate between the one-year correction period and the contractor’s warranty

A

The difference between the two is the duration. The one-year correction period, as its name implies, contractually obligates the contractor to repair defects for a one-year period after
completion of the project; whereas, the contractor’s warranty extends beyond the one-year period and is subject to individual state statutes of limitations. The owner’s remedy after the one-year
correction period should the contractor not respond is to correct the problem and seek recovery of cost through legal means.

102
Q

Define Final Completion

A

Final completion occurs when the contractor has completed the contract requirements, the architect/engineer has inspected the project to determine it is indeed complete, the owner has
made final payment to the contractor, and the contractor has accepted final payment.

103
Q

Describe the activities that culminate in Final Completion

A
  • Contractor completes work on the punch list
  • Contractor removes any remaining tools, materials, equipment, trash, and temporary facilities
  • Contractor submits final completion closeout documents including final application for payment
  • Architect/engineer inspects project to verify that all punch list items are complete
  • Architect/engineer certifies final application for payment and forwards to owner
  • Owner makes final payment to contractor
104
Q

Which of the following is established by the architect/engineer’s verification of the completion of punch list items, the processing of the final application for payment, and owner’s payment?
a.) Substantial completion
b.) Project closeout
c.) Final completion
d.) Final inspection by AHJ

A

c.) Final completion

105
Q

True or False?
The architect/engineer should have prepared the initial punch list.

A

False

106
Q

Which of the following best describes the situation had the freight elevator not been approved by the AHJ in time for the substantial completion inspection?
a.) The architect/engineer would approve substantial completion since the contractor was trying to get the issue resolved
b.) The architect/engineer would not approve substantial completion because if the elevator is not working properly then there may be other issues of which the architect/engineer is unaware
c.) The architect/engineer would approve substantial completion on a conditional basis
d.) The architect/engineer would not approve substantial completion since the owner would not be able to use the building for its intended purpose without the freight elevator

A

d.) The architect/engineer would not approve substantial completion since the owner would not be able to use the building for its intended purpose without the freight elevator

107
Q

In which division is the section “Starting and Adjusting” located?
a.) Division 01—General Requirements
b.) Division 11—Equipment
c.) Division 23—Heating, Ventilating, and Air Conditioning
d.) Division 46—Industry-Specific Manufacturing Equipment

A

a.) Division 01—General Requirements

108
Q

The first submittal prepared by the contractor is which of the following?
a.) Project record documents
b.) Operation and maintenance data
c.) Demonstration and training
d.) Spare parts, extra stock materials, and tools

A

b.) Operation and maintenance data

109
Q

Identify the closeout activities in which the facility manager is
involved

A

The facility manager will be involved in the following closeout activities:
* Closeout meeting as an attendee
* Observing commissioning activities
* Review and become familiar with closeout submittals
* Start-up of systems
* Review warranties

110
Q

When are the commissioning activities be conducted?

A

If commissioning is part of the project, commissioning activities will be conducted throughout the construction and will be completed during project closeout. If commissioning is not a part of
the project, the owner may hire a commissioning authority to provide expertise during closeout. These activities include participating in the demonstration and training and the
start-up of systems.