My Submission Flashcards

1
Q

ethics

What are the five rules of conduct?

A
  1. Act with honesty and integrity
  2. Maintain professional competence
  3. Provide a good quality and diligent service
  4. Treat people with respect and dignity
  5. Act in the public interest
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
2
Q

What are your professional obligations to the RICS?

A

To complete 20 hours of CPD annually, with 50% being formal.
Provide any information requested by the RICS promptly
Cooperate with the RICS

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
3
Q

What are firms’ professional obligations to the RICS?

A

Provide an annual return to include;
PI Details, any complaints, type of business, nature of clients, any training and further information requested.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
4
Q

Provide an example of where you acted in accordance with the Five Rules of Conduct or your company’s policies.

A

Following the success of a previous scheme, the Contractor provided their Client with my details to offer our services. Upon discussion with the Client, I was unable to offer the services under our Professional Indemnity Insurance and so could not offer our services. I did then advise on the services we could offer as an alternate proposal.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
5
Q

Provide an example of where you have dealt with a conflict of interest/ ethical issues.

A

When certifying a valuation, the Employer advised that the value should be below a certain value in order to benefit their cashflow. As CA, I noted this was a conflict of interest and could not do that as would be acting biasedly under my appointment. I therefore advised I had to act in accordance with my scope of service as a QS and value the works fairly.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
6
Q

What would you do if a Contractor offered you a gift at Christmas?

A

I would refer to my company’s gift policy. Dependent on the value of the gift, I would either disclose this accordingly or reject the gift politely and advise why it could not be received,

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
7
Q

How would you compile an appointment?

A

I would initially understand the Client brief to confirm what services are required. Once agreed, I would confirm any exclusions within this scope of service. For example, typically RPP would exclude analysis of extension of time claims. I would then agree the fee for this works. In addition, I would ensure the scope of service are covered under our PI.

I have not produced an appointment however would ensure it aligns with the RICS standard form.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
8
Q

How would you agree a fee proposal?

A

I would review the scope of service and compile and activity schedule which schedules out my roles and responsibilities, and allocate an estimated amount of time per activity times by the hourly rate to provide a lump sum. Alternatively, I would include a percentage of the contract sum, as adjusted in the FA.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
9
Q

What would you typically exclude from a cost plan?

A

Land acquisition fees, design fees, inflation, insurances, working outside of normal hours, asbestos removal, fluctuations, phasing, fees

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
10
Q

How do you manage a new client/ a new project?

A

I ensure all processes are agreed with the Client prior to commencing the works. For example, I would confirm their preferences for reports such as how frequently these are required. In addition I would ensure to act professionally and provide my scope of service as agreed.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
11
Q

How do you issue reports to the Client?

A

I ensure reports are issued at the frequency agreed, I provide the information in a coherent and easy to understand manner, provide any further supporting information or narrative as required and ensure the opportunity to discuss this further is provided. For example, when issuing a tender report, I scheduled a call for the following day after the report was issued, to allow time for the Client to review this and then provide the opportunity to review the report over a teams call to present and discuss in more detail and answer any initial queries.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
12
Q

What do you understand communication to be?

A

I understand communication is the process of exchanging information and can be completed in different manners such as verbally, in writing, online over email or through other mediums.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
13
Q

What do you understand negotiation to be?

A

The process of concluding a disagreement to reach an agreement between parties.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
14
Q

How do you present written communication?

A

I ensure written communication, such as via emails, is professional, grammatically checked and issued to the correct personnel. I understand that emails can be used in court proceedings and considered written instructions and so must take care when issuing any information.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
15
Q

How do you manage negotiations?

A

I ensure to provide a professional and calm environment where all parties are allowed to present their opinions without interruption. I understand the benefit of including a mediator who is unbiased and not involved in the disagreement to manage the process.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
16
Q

How would you structure a progress meeting?

A

I would begin my ensuring all parties have met each other and undertake apologies and introductions. Following this, I would review outstanding actions from the previous meeting. Then, I would include a section for the contractors report to be delivered to include an update on programme and any issues to report or discuss and then followed by Consultant reports/ matters to pick up design issues. following this, I would provide a CA/EA report. Then, any employers matters, followed by any other business and agreeing the time and date for the next meeting.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
17
Q

How would you formalise verbal communciation?

A

If via a call or in person, I would issue an email / written communication to confirm the discussion and request that the other party, by return, confirms their agreement to the record of the conversation. If in a meeting, I would record this in the meeting minutes and circulate to all parties for their review.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
18
Q

can you provide an example of where you negotiated costs?

A

I frequently negotiate variation accounts, final accounts and tenders. For example, on a car showroom scheme there were a large number of changes and so these were reviewed and negotiated in detail to agree fair and reasonable costs for the works. I would obtain quotations for the works or alternatively carry out my own estimate and compare the two to review with the Contractor.

FA: Costs submitted by C for additional works required to complete the scheme. Omitted in initial discussions as no change under Clause 5.1 however reviewed with Client to determine fair and reasonable, reviewed costs fair and acceptable to both parties and agreed this.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
19
Q

What do you include in an Employers Agent Report?

A

On the BMW Car showroom scheme, I was responsible for both the main contract works and directs packages and so the Employers Agent report provided an update to the Employer on both. The report included key progress in the last period, activities in the coming month, any delays to report, key risk items and their owner/level of risk, outstanding information from any parties, including the employer and a general update on the direct packages i.e. timescales, works to complete etc.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
20
Q

What is the main Health and safety legislation?

A

Health and Safety at Work Act (1974)
Identifies responsibility of the Employer and Employees when at work to keep themselves and others safe.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
21
Q

What are the CDM Regulations?

A

Aim to improve health and safety in the industry by providing rules and guidance on health and safety and planning.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
22
Q

What is the structure of the CDM Regulations?

A

Introduction.
Part 1 - Commencement, interpretation and application.
Part 2 - Client duties.
Part 3 - Health & Safety Duties and Roles.
Part 4 - General requirements for all construction sites.
Part 5 - General.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
23
Q

How do you mitigate exposure to asbestos?

A

Undertake an asbestos R&D survey prior to commencing works. If asbestos is discovered, clear the area, do not disturb it, remove any clothing that may have come into contact, wash yourself and prevent further disturbance until it can be reported and the relevant action taken place

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
24
Q

What CSCS card do you hold?

A

I undertook the Manager and Professionals course and have obtained a red apprentice card.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
25
Q

How do you reduce your risk and others, on site?

A

I ensure I am wearing the required PPE and have received a site induction prior to entering the building site. I report any health and safety hazards on site.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
26
Q

Provide an example on when you have reported on a risk to H&S at work?

A

I have reported on the incorrect segregation and safety of a construction site. Following sectional completion, the site was clearly divided into two where the Employer took possession. The Contractor had failed to clearly segregate the two areas which allowed staff from the other area, and the public, to enter the building site. I notified the site manager of this and ensured it was recorded via written communication to the contractor and client.
I have also advised and reported on unsafe use of equipment such as labourers using a scissor lift and wooden pallet to wark at height.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
27
Q

What are the main accounting documents and what are these?

A

Profit and loss statement - shows a company’s revenue resulting in either a profit or loss.
Balance Sheet - Shows assets and liabilities. (income vs debt)
Cashflow statement - shows a company’s incoming and outgoing expendire over a period

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
28
Q

How would you advise a client to finance a construction project?

A

I would suggest numerous options to allow the Client to decide how best to proceed. These would include bank loans, grants and private company investment. In addition, on a recent scheme, the works were phased and the Client used the profit from the first phase to finance the second development and so I would also suggest this if it applied to the client.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
29
Q

What are the basic elements of a business plan?

A

A business plan will include an exec summary, a marketing summary, business description, financial plan, company structure, any objectives or goals and the financial analysis. For example, I my company’s business plan includes the main objectives which allows me to understand how I can contribute to this such as through professional development, repeat work and mitigating the cost of the scheme exceeding the agreed fee.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
30
Q

What are RPP’s company goals

A

Encourage repeat work, develop a nationwide business through an equal share of turnover across the national offices, cost positive projects that do not exceed the agreed fee, CPD and improved communication with staff.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
31
Q

How do you avoid conflict?

A

Ensure to maintain professional relationships, carry out my scope of service professionally and as agreed, keep records, carry out good management, provide solid tender and contract documentation that clearly outlines responsibility and report regularly.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
32
Q

How would you deal with a dispute between parties where you are administering the Contract?

A

I would initially aim to resolve any conflict without escalating to court proceedings. This would include creating an environment where the conflicting parties can have an open discussion in an environment where they can present their opinions without interruption. I would ensure any relevant records or information are provided to inform the discussion and aim to resolve the conflict without escalation. Failing this, I would review alternate dispute resolution processes as in the contract and with a senior colleague to advise the client accordingly.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
33
Q

How have you assisted in dispute resolution techniques?

A

Although I was not involved in any processes beyond this point, I assisted a colleague by producing a SCOTT schedule which set out the allegations in the dispute and each parties comments to assist in the proceedings.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
34
Q

What are the main types of dispute resolution

A

Mediation - third party assists in reaching an agreement to settle the dispute. Is not binding but is a low-cost solution.
Arbitration - private tribunal determines binding settlement. If applies, must be carried out as TCC may ‘stay’ litigation proceedings if not.
Adjudication - 28 day time frame where nominated adjudicator determines binding decision - court
Litigation - can always be used - legally binding court proceedings - TCC

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
35
Q

Can you advise on types of reliable cost data

A

I would ascertain cost information from in-house cost data from recent tender returns, cost estimates or cost plans, or use pricing information such as SPONS or BCIS. I understand the requirement to adjust the rates accordingly, such as updating older data using Tender Price Indices on BCIS.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
36
Q

How does your Employer store internal data?

A

My Employer uses a common filing system that all QS’ use which enables greater collaboration. The data is stored and then archived once the scheme becomes historic i.e. after the 6 / 12 years have exceeded.
Cost data is also uploaded to a cost analysis storage point so it can be accessed by all employees.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
37
Q

How does the data protection act impact storing data

A

I understand that the data protection act effects how different types of data should be used and stored. I am aware that data should be used fairly, lawfully, transparently, for the purpose of its use and stored privately and securely. Therefore, if there were confidential information that should not be stored on the shared system, I would discuss this with my Client and Employer to arrange a separate platform for this to be stored.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
38
Q

What do you understand as diversity, inclusion and teamworking?

A

I understand diversity and inclusion are important in creating a fair working environment for all. I am aware that we must protect others from discrimination and treat everyone fairly without bias. Teamworking is also essential to providing a collaborative environment and progressing a project efficiently and successfully. To encourage teamworking, I have recently used platforms such a sharepoint for all information to be shared where all members of the team have access.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
39
Q

Can you provide an example of inclusive environments on a project?

A

I understand that construction projects must accommodate for all parties and ensure that the schemes result in a building that is accessible for all. I would refer designers to Approved Document M which sets out the minimum standards. I have also worked on the Yorkshire Big Build Scheme which develops and helps SEND Schools. From this, I am aware of further requirements such as sensory needs, wheelchair access, external space requirements for larger vehicles.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
40
Q

What is sustainability

A

Sustainability is the development that meets the needs of the present without compromising the future generations ability to meet their needs.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
41
Q

Can you provide examples of sustainability accrediation and how these can be met?

A

I am aware of the BREEAM accreditation and that this is based on criteria of different categories. I understand that some are mandatory and others are optional to achieve higher ratings. For example, criteria within the materials category can be met by sourcing lower-carbon materials and reducing transport required. Although I have not used them, I am also aware of different accrediations such as NEBAR’s and LEED.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
42
Q

What are SDG’s

A

SDG’s are the sustainable development goals outlined by the UN to encourage sustainability and eradicate issues such as poverty.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
43
Q

How can the construction industry assist in the net-zero targets?

A
  • encourage the use of sustainable methods and materials
  • improve training and skills
  • retrofit existing buildings
  • progress the legislation
  • reduce waste
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
44
Q

What is an elemental cost plan?

A

An elemental cost plan breaks down the construction works into elements to include;
substructure, superstructure, internal walls, internal finishes, FFE, Mechanical and Electrical installations, drainage and external works.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
45
Q

When are cost estimates and cost plans carried out

A

A cost estimate sets the budget and allows the Client to review the affordability of the scheme. This is produced where there is limited design information at RIBA Stage 1. A cost plan is a working document that develops with the design and sets out the target cost - this is developed between RIBA stage 2-4.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
46
Q

What are the types of cost estimate/plan?

A

Functional unit - unit x rate (i.e. nr of student beds x cost)
Floor area - GIFA x m2
Elemental - works broken into elements and quantified - quant x rate

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
47
Q

Can you advise on factors that effect a cost plan?

A

The cost plan will depend on the buildings size, location and function. The cost plan will also consider any abnormals.
Cost plans should be adjusted on the above using BCIS

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
48
Q

What is a PTE and why is it required?

A

The PTE is the Pre-Tender Estimate which is the final cost plan carried out based on the tender information issued to contractors. The PTE provides a document which can be used to analyse against the tender returns and also updates the Client on the most recent design and information.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
49
Q

What is contingency and what levels should be included?

A

Contingency is an allowance included within an estimate or cost plan to caveat any unforeseen increases, unknown expenses or unmitigated risk.
At RIBA stage 1-2, the design information is limited and so a higher contingency is included whereas as the design develops, the cost plan is developed in more detail so is more accurate and so contingency is not required. 5% at RIBA 2-4 10% 1-2

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
50
Q

How do you sense check a cost plan or estimate prior to issuing to a client?

A

I ensure to sense check all documents issued to a Client. for example, on the industrial schemes in Harrogate, I compared the cost report to in house recent cost reports of a similar scope on a cost/sq ft basis. When doing this, I ensured to take into account any abnormals so was an equal comparison. In addition, I would review recent tender returns or check against the average costs included within spons.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
51
Q

What is Value Engineering and how would you conduct this process?

A

Value Engineering is the process of providing alternate solutions to the Employer to reduce the cost of the scheme. If a cost plan was over budget,I would suggest arranging a meeting with the design team to review the design and for any proposals to reduce the cost of the scheme to be provided and discussed. I would ensure that this does not impact the Employers key priorities or any specific requirements that were discussed in the client brief. I would also I would review any elements that stand out as expensive. and suggest these to provide proposals to the Client.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
52
Q

Can you provide an example of where you have assisted in a value engineering process or advised on alternate solutions?

A

I have reviewed different proposals to provide cost options to the client to reduce the cost, such as pre-fabricated valet bays that were manufactured off-site. These reduced the programme and cost and so the design was amended following the cost exercise.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
53
Q

How would you advise on proceeding if a cost plan was over budget?

A

I would suggest to undertake a value engineering workshop with the design team to provide proposals for areas where cost savings can be made.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
54
Q

How would you include prelims within a cost plan?

A

At early stages, I would include an allowance based on a percentage of the contract sum - usually between 10-20%.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
55
Q

What are the main differences between traditional JCT Contracts and the Design and Build Contracts

A

The main difference between traditional and D&B is the allocation of risk. Under a traditional contract, the design and risk remains with the Client but this also offers further control. Whereas, the Design and Build contract transfers all risk and responsibility of the design and construction to the contractor, thus removing some control of the quality but reducing the design risk for the Employer.

Risk: Sole point of responsibility under D&B and transferred to C whereas traditional, risk could be placed on any consultant and C

Cost: risk premium with D&B as risk allowances priced into scheme were design less detailed whereas traditional, design complete so priced accurately
More cost certainty under D&B unless any changes - under D&B priced higher

Programme: Programme length reduced on D&B as design being undertaken in tandem with construction.

Design: risk transferred to C under D&B but also E retains less control over design on D&B

Tender analysis: Easier to compare and analyse traditional as all based on exact design. Under D&B, more scope for variation of the design proposals submitted by C so more difficult to analyse submissions

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
56
Q

What are the benefits of traditional procurement?

A

The client retains control over the quality and design

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
57
Q

The client has requested your advice on which contract to use on a contract where there is minimal design complete and the aim is to start works as soon as possible? What procurement route and contract do you suggest?

A

I would suggest a single stage tender process on a design and build contract to obtain a cost for the construction of the works and further development of the design. This will enable enhanced collaboration and benefit from using the Contractors expertise to complete the works. In addition, this will reduce the programme as design and construction can overlap. This will also reduce the design risk for the Employer.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
58
Q

The client has proposed a scheme which includes small works of a simple nature. Which contract would you suggest.

A

I would suggest the Minor works JCT Contract. I would query whether any contractors design is required to be able to advise on whether MW with design is required.
I would confirm that the Employer is aware that this comes with less detailed contract provisions and that the Employer retains control of the design and subsequently design risk

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
59
Q

If you were unsure on which contract to select, how would you advise a client?

A

I would refer to the JCT Guidance Document called ‘Deciding on the appropriate JCT Contract’ and review this depending on their requirements.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
60
Q

How do the mechanisms differ between traditional and D&B

A

Traditional contracts require the CA to cerity a payment certificate as per the contract particulars, irrespective of a contractors application in line with the dates set. Whereas, D&B payment terms are triggered by the contractors application and is contractor led.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
61
Q

What do you do if the Contractor fails to meet practical completion.

A

I would refer to the Contract to understand the mechanism required however I do understand on a D&B contract that a non-completion notice must be issued to certify that the contractor failed to meet PC. The non-completion note must be issued in order for the Client to levy damages, if he wishes.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
62
Q

How are provisional sums adjusted?

A

Provisional sums are adjusted via Instruction from the CA or EA and are omitted from the contract sum. The agreed cost is then added back in to account for the actual cost of the work.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
63
Q

What does Sectional Completion mean?

A

The works are divided into sections to phase the works, such as on a scheme in Crewe which allowed early possession to some areas. One section 1 was complete, retention was released as per the contract and making good defects complete for that section after 12 months.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
64
Q

What should you do if a contractor does not submit an application on a D&B job?

A

If the Contractor failed to submit a valuation by the due date, I would advise the Contractor of this to remind them that an application was due. Subsequently, I would advise that the due date will then become 7 days after receipt of their application. If no application was received, I would not issue a payment notice as one is not due under the contract.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
65
Q

What would you do if a Contractor does not submit an application on a Traditional job?

A

If an application is not received on the valuation date, I would ensure to undertake my own valuation of the works and issue a payment notice certifying the amount I believe due, in line with the payment dates listed in the Contract.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
66
Q

What are preliminaries?

A

Preliminaries are a group of items necessary for a contractor to complete the works but do not become part of the finished works. They also define the contract particulars which will form part of the contract documents.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
67
Q

What quality management processes do you undertake when issuing contract documents?

A
  • refer to the contract document checklist that forms part of my company’s QA process;
  • comp check the pricing document
  • ensuring the list of drawings is correct and matches the exact drawing name.
  • preliminaries and contract particulars align - Contract sum in contract and pricing doc align
  • All documents signed by a senior surveyor and director
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
68
Q

How does retention work?

A

Retention is a percentage of the contract sum retained by the Employer to rectify defects and other works on the basis that the contractor does not complete the works. The percentage is defined in the contract particulars - usually 3%. 50% is then released at PC with the remaining retention released, usually upon receipt of the making good defects certificate.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
69
Q

What is the due date for final payment?

(end of project - last payment)

A

one month after whichever occurs last of:
- end of rectification period
- date stated in MGD Cert
- Date of submission of the Final Statement

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
70
Q

Provide an example of where you have certified works?

A
  • Certifying valuations
  • Certifying practical/ sectional completion

(Crewe - issued PC)

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
71
Q

Can you provide an example of where you have advised on the impact of schedule of amendments?

A

Advised the Contractor of the increase to payment terms of 28 days rather than 14
Advised the Contractor of their responsibility to verify the design and take responsibility for the design pre-contract.
This further supported the Clients claim that the Contractor was not due the sums for additional groundworks required as a result of poor ground conditions

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
72
Q

How would you advise a client if they had suggested they wished to withhold payment?

A
  • breach of Contract
  • would give the Contractor rights to terminate the Contract under Section 8.
  • to pay the Contractor in line with the final date for payment listed on the payment notice
  • alternatively issue a pay less notice, if there was adequate reason in line with the contract.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
73
Q

A Contractor is not progressing with the works and causing delays to programme, how would you proceed?

A
  • raise my concerns over the delays to programme and query this with the Contractor & highlight this is a breach of contract.
  • Understand the reason for the delays and discuss this to understand if there is cause/ any way to assist in mitigating the delays
  • If the Contractor continued to fail to proceed regularly, I would issue a notice under Clause 8.4 of a D&B Contract.
  • If the default continues beyond 14 days, I would seek legal advise and note to the Employer that they are able to terminate the contract after 21 days of expiry of the 14 days
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
74
Q

What is insolvency?

A

The inability to pay debts. If a party becomes insolvent, the other party has a right to terminate the contract.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
75
Q

Please provide examples of sustainable methods and materials

A

pre-fabricated materials
modular building
mass timber
recycled steel
pre-fabricated steel
glass
pre-cast concrete
reduce waste
reduce transport
retrofitting

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
76
Q

Please can you provide an example where you have advised on the design of a building?

A
  • pre-fabricated valet bays/ traditional build based on cost, programme and more environmentally friendly
  • safeguarding in a residential building - arch proposed requiring key cards to exit the stair well, I advised this could end in where someone had tailgated in and the resident could become trapped in the stair well.
  • Advised on the solution for a design flaw where the duct work was below the ceiling grid line - solution was to proceed with a cupboard to provide usable space rather than boxing in.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
77
Q

Can you provide an example of where you have made assumptions in your cost estimates

A
  • Trafford Centre - 2hr party walls rather than 1hr as per building regs. Included allowance for removal of existing and replacement with new screed as usually requested by tenants in AFL.
  • Schemes for Lookers and assuming direct packages required based on previous schemes; new signage, furniture packages, IT allowances, surveys required etc.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
78
Q

If the Employer requests a significant change to the scope of works, how would you proceed/ advise

A

Confirm the change
Advise on any initial risks i.e. cost / programme
Discuss with Contractor
request the C prices and provide cost and programme impact to the client for instruction

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
79
Q

Can you provide an example of where you have highlighted that the works are not in accordance with the ER’s

A

On BMW Crewe, there were numerous instances where the contractor had attempted to recover costs by not carrying out the works in line with the ER’s such as installing the incorrect barrier hoops.

  • advised the Contractor that the installation was incorrect
  • Issued an instruction for the removal of the works that were not in accordance with the contract
  • ensured the rectified works were correct
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
80
Q

What is METSEC?

A

METSEC is an external wall system comprising of a steel frame that is pre-fabricated and provides quick installation on site to allow the construction of other elements in tandem with the frame

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
81
Q

What are the advantages of precast concrete?

A

Controlled environment - better quality control
Faster install to reduce construction programme
less susceptible to cracking
weather resistent

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
82
Q

What are the disadvantages of precast concrete?

A

Requires plant and transport as is heavy
Must be handled with care as if damaged on site, must be re-manufactured

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
83
Q

What do you understand as single stage tendering

Advantages/ disadvantages

A

Single stage tendering is the issue of the final tender documentation a a number of contractors, usually 4, to price. The tender returns are then provided and analysed with one contractor selected. Single stage tendering is carried out from RIBA stage 4.

  • competitive tender returns based on more detailed tender information
  • longer design periods required to ensure information acceptable to obtain price for the entirety of the works
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
84
Q

What do you understand as two stage tendering?

A

Two stage tendering is the process of issuing the tender documents, usually where the design is not fully progressed, to obtain prices and proposals for the works. One Contractor is then selected and the scheme is progressed to complete the design process. Two stage tendering can be carried out from RIBA Stage 2.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
85
Q

What is open tendering?

A

Open tendering is the process of issuing an invitation to tender and tender documents on an open forum, through public procurement sites/ frameworks, where anyone can submit a tender.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
86
Q

In what situation would you suggest a two stage tender?

A

Schemes where the design is not fully complete
Where a D&B contract is to be used
Where the scheme would benefit from contractor/ specialist input

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
87
Q

When would you suggest a single stage tender?

A

Where the Employer wishes to retain control of the design through the design stages
Where the design is complete/ developed enough to obtain a price with minimal risk inclusions
On a traditional scheme
On a D&B where the E wishes to have more control over quality

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
88
Q

What procurement route would you suggest on a public sector scheme?

A

Although I have not worked on one, I would advise the Client to check their policies for procurement. I would note that open tendering or two stage would be preferable based on public procurement legislation such as PPP.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
89
Q

What is included within preambles/

A

The minimum specification / standards

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
90
Q

What is included in an invitation to tender?

A

Introduction
Purpose and scope of ITT
Scope of project
key dates (tender process to appointment)
tender documents
form of contract]project team
information to be submitted as part of tender
evaluation
confirmation of intent
any assessment information

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
91
Q

What is traditional procurement and where would you use it?

A

Design, bid, build
E employs a design team, tender information is issued to contractors, contractor appointed based on price, E retains control of design and C constructs works in line with Spec/Drawings.
Price certainty, transparent, competitive, comparable
No input from C on design, E risk if design errors/ not complete
Used where design complete, E wishes to retain control, smaller schemes

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
92
Q

What is design and build procurement and where would you use it?

A

Contractor is responsible for the design and construction for an agreed lump-sum price
C assumes risk, quicker procurement process, price certainty
less control over design, pay premium due to risk, changes can be expensive, harder to analyse tenders
Used where design not as developed, reduce prog, E wishes to reduce risk, not as much control over design required

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
93
Q

What is construction management and where would you use it?

A

Construction manager appointed by E to manage the different packages of works.
All works split into packages and tendered to receive prices - competitive. Design & construction overlap, reduce programme
No price certainty until all packages let, delivery can be challenging, requires good managing
Use where clients are experiences, hands on and working relationships are strong - can be used where aim is to reduce programme and costs but does not require price certainty

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
94
Q

What is management contracting and where would you use it?

A

Design completed by design team, E employs management contractor to manage whole of the works. C appointed through tender or negotiation. Works contractors then complete the works (packages). Design can be in parallel with construction, no certainty of cost, cannot make changes that effect other packages, any gaps can cause issues.
Use when projects complex in nature but E wishes to retain control of design

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
95
Q

Provide an example of where you have carried out a negotiated tender?

A

Pannal:
First phase ongoing - contractor successful
Second phase to be tendered - agreed to negotiate with same C as first phase
Obtained a price, compared to PTE and previous scheme as similar in nature.
Negotiations between Employer and C - commercial saving on the contract sum in return for an advance payment of 10%.
Both parties agreed.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
96
Q

How do you review contractors proposals?

A

I initially ensure the CP’s are compliant with the ER’s by reviewing the proposals in detail. Once satisfied, I would set out the criteria as agreed with the Employer to create a scoring system with weights assigned. I then undertake this exercise and review each proposal, assign the scores to the scoring matrix and determine the best proposal based on the highest score.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
97
Q

Can you provide an example of where you reviewed contractors proposals?

A

On a scheme in Harrogate, the Contractor had proposed programme and cost savings for different solutions to those listed in the ER’s. I ensured the overall lump sum was compliant with the ER’ and that these would be offered as savings. This was confirmed so the tender returns were analyzed on a comparable basis, and the proposals raised in the tender report to the Employer.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
98
Q

How would you advise on incorporating changes post-tender

A

I would provide the Contractor with the revised information for pricing and for any impact on programme to be raised. I would also undertake my own analysis of the changes and estimate the cost impact. Following this, I would agree the contract drawings with the Employer and Contractor to ensure all parties are aware of the contents and associated costs.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
99
Q

What would you include in a cost report?

A

Project summary (key dates)
Contract sum
Adjustments of the contract sum, as per those listed in the contract, i.e. adjustment of provisional sums, client contingency, any instructions and changes, foreseen changes.
Any fluctuations if applicable
Any deductions if applicable
cashflow (if required)

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
100
Q

Why should costs reports be provided frequently

A

To regularly update the Client on forecasted/additional expenditure and estimated final account.
Informs requirement for further funding

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
101
Q

How should provisional sums be adjusted?

A

Omitted from contract sum via instruction
Addition of actual cost added to contract sum as an adjustment

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
102
Q

How do you identify different packages on a cost report

A
  • clearly segregate the two
    On BMW, all costs were included within the same board approval figure, however I adjusted each package on different tabs to clearly segregate the direct packages, main contract package and the EV works. This allowed the Client to see the adjustments for each elements, rather than overall cost for the works as a whole.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
103
Q

What are variable costs?

A

Those to be adjusted i.e. provisional sums, PC sums, quantities, dayworks

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
104
Q

What are variations?

A

Changes to the Contract Documents as listed in the Contract i.e. client instructions, loss & expense, fluctuations, design fees added as result

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
105
Q

How do you calculate and present a cashflow?

A

The cashflow provides an estimated cost to be invoiced each month for the duration of the project. In the first instance I would request a cashflow from the Contractor. Failing receipt of this, I would calculate an estimated forecast based on programme activities and the pricing document. On BMW Crewe, I also provided a cashflow for the directs which was calculated based on when the works would be carried out on the programme. Some requested payment upon receipt of order and so this was split accordingly on the cashflow.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
106
Q

How do you manage a cost report and client contingency?

A

Any adjustments to contingency are clearly shown on the cost report to identify the total remaining.
On a traditional job, it was agreed with the Client that it is at my discretion to use the contingency where required. On this basis, where additional unforeseen costs have been incurred, I have offset these against the contingency such as additional NPG connection expenses.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
107
Q

What are defined and undefined provisional sums

A

Defined = programme allowance included
Undefined = no allowance for programme

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
108
Q

Can you provide examples of different quantification techniques you have used

A

Floor area, functional unit and elemental.

I have frequently used the elemental technique to produce cost plans and quantify works. Using this, I have measured the approximate quantities of the works required and applied rates using reliable cost data to produce a cost plan.

I am aware of how to use other methods but have not used these recently.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
109
Q

can you give an example of producing pricing documents?

A

D&B - I have produced CSA’s for numerous jobs on d&b schemes where these have been detailed or simple summaries.
Traditional - I have produced work schedules for minor works with design jobs. I am aware of the importance to ensure all items shown on the design information are reflected in the work schedules and that any elements that are contractor designed should be clearly defined.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
110
Q

Where would you use NRM2

A

I would apply NRM2 when producing bills of quantities.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
111
Q

Where would you use NRM1

A

I would use NRM1 for assistance in cost estimating and cost planning

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
112
Q

Where would you use NRM3?

A

Although I would not use NRM3, I do know it should be applied when producing cost plans/estimates for maintenance works.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
113
Q

Can you give an example of where you have used NRM?

A

I have used NRM when producing cost plans for assistance in ensuring all components of an element are included within my costs. For example, ensuring that I have made allowances for mat wells that may not be shown on the drawing but will likely be required.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
114
Q

What pricing documents are there?

A

Tradtional :
With quantites - BoQ
Without quantites - Works Schedules, Specifications (+drawings)

D&B: CSA

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
115
Q

How would you advise a employerwhich pricing document to use?

A

If there was not sufficient design information, i would advise on a D&B contract with a CSA.

If the design is complete with some CDP portions, I would advise on either a work schedules or specification without quantities.

116
Q

How have you assisted in producing a bills of quantities

A

I have assisted in preparing BoQ once, where I used CATO to complete the wall finishes section. I used NRM 2 to ensure the descriptions were correct and using the correct coding.

117
Q

When costing construction works, how would you caveat where there is not sufficient design information.

A
  • increase the design contingency
  • query elements with the architect
  • clarify any assumptions made
  • clarify any exclusions
118
Q

How much contingency should be included?

A

RIBA 1-2 - 10%
RIBA 3-4 - 5%

119
Q

How would you proceed in negotiating a final account

A

(BMW)
Initially I would determine which items I agree with in principle and which should be rejected. I would then request the relevant substantiation to those to be considered in the discussion i.e. breakdown to costs, quotes etc. and any further narrative.

I would then review these and advise on those I disagree with to negotiate the fair and reasonable cost to be included and agreed.

For those rejected, I would then review once all other items were concluded to negotiate these on a fair and reasonable basis between all parties to ultimately conclude the account.

Following agreement, I would issue a final account statement to formalise this.

120
Q

How do you draw down interim valaution payments?

A

Track against cashflow and programme
Undertake valuation on site to value works undertaken since commencement
Sense check against programme and actual works complete
sense check against cashflow
If works in delay, would anticipate that the valuation should not exceed the cashflow

121
Q

When a contractor returns the contract documents prior to the Employer executing, what checks should you undertake?

A

Signed in correct place and as per letter issued with contract docs listing requirements
not dated
check no hand written amendments

122
Q

How do you structure a risk workshop?

A

I would issue a risk register to all parties prior to the meeting for their consideration.
The meeting would then focus on reviewing the risk register and adding any additional items - all parties to review and consider the risk of each item to highlight critical items and discuss any potential mitigation strategies. Frequent meetings to review.
For example, Trafford Centre M&S - undertook fortnightly meetings to review the long lead items, orders placed and the potential impact on programme and the risk of not meeting the notice periods and black out dates.
Reviewed notices with Employer so all met.

123
Q

If you consider items within a legal document to be a risk to the Employer, how would you proceed?

Example?

A

I would review the document and highlight any clauses which may put the Employer at risk or that are not achievable and arrange a meeting to review these and understand the position. I would also ensure the document was issued to any other consultants for their review and comment.

Trafford Apple AFL - reviewed, highlighted, discussed, E position confirmed, negotiated with tenant

124
Q

When should you use ICD?

A

Where a scheme is not complex in nature but requires detailed contract provisions, the Employer wishes to retain control of the design.

125
Q

When should you use MWD

A

Where a scheme is small in nature, E wishes to retain control

126
Q

When should you use D&B

A

Where E wishes to transfer responsibility of design and then construction to contractor, larger projects where design not fully complete

127
Q

When should you use Standard Building Contract

A

Not used it but - When the scheme is large or complex, detailed provisions needed and E wishes to retain control of design

128
Q

What is the CA’s role

A
  • administer the contract
  • Certify in line with contract - completion, payment
  • Notify - termination, payment, dispute resolution
  • Supervise works, approve quality, issue instructions, make assessments
  • Provide information, IRS
129
Q

Can you provide a summary of your role when undertaking the CA role?

A

I administer the contract, issue notices, supervise and approve the works, chair monthly progress meetings, issue instructions, certify payments, certify completion and undertake any other requirements as per the Contract.

130
Q

How do you manage the payment process?

A

I initially review the amendments and confirm any adjustments to the payment terms and then set up a payment schedule which identifies the key dates such as the valuation date, due date, final date for the payment notice and final date for payment.

This is based on the dates as per the contract however may adjust on a D&B contract where the application is received beyond the due date.

Pannal schedule - where QS only and tight payment dates - agreed date for final issue of valuation certificate

131
Q

How do contract amendments effect the contract?

A

The amendments amend the terms of the contract, the most common is the amendment of the payment terms from 14 days from the due date to 21 or 28. I ensure to review the contract amendments in all circumstances when referring to the contract.

132
Q

If the Employer requested a change to the ER’s, how would you process this?

A
  • Request the contractor to price the change and advise on any programme implications
  • advise the Employer of this
  • Review the costs submitted, ensure fair and reasonable, request approval
  • Instruct the works

Where works require an extension to the programme, I would make note of this on the Instruction that there is a resultant programme impact, and would then issue a notice to adjust the completion date accordingly. I would also ensure any costs reflect the actual costs i.e. prelims etc, included.

133
Q

How do you certify PC?

A

To certify PC, I would ensure that the works are substantially complete, save for any minor defects, and the building could be occupied

I would ensure that the Contractor has provided the information required to grant PC, specifically sign off from Building control, the health and safety file and O&M information.

134
Q

What would you expect to find in O&M’s

A

As-built information
Details of the project
Details for operation and maintenance of the building and installations
Warranties
Guaranteed
Testing and Commissioning Certificates
Building Control sign off

135
Q

What would you include on a PC certificate

A

The date of the contract being signed
The date that practical completion was granted
The date for the end of the rectification period
A list of outstanding works/ snags
Append the snagging list
Timescales for completion of outstanding items (usually 14 days)

136
Q

What do you do if the Contractor does not meet PC

A

Dependent on the contract, I would issue a non-completion certificate.

If one is not required, I would formally notify the Contractor and Employer that PC had not been met through written communication to keep a record of this.

137
Q

If the Employer wished to levy damages how would you proceed?

A

I would refer to the relevant clause in the Contract as the mechanisms differ between the JCT contracts.

Under a D&B I would advise the Employer that notice to levy damages must be given prior to 5 days before the final date for payment and that the notice must comply with the information requested under the contract.

138
Q

What is GAAP?

A

Generally Accepted Accounting Principles

Accounting standards and practices utilised by businesses in the preparation of their financial statements

139
Q

What is IAS?

A

International Accounting Standards

Set of accounting rules - Replaced in 2001 by IFRS

140
Q

What is IFRS?

A

International Financial Reporting Standards

Set of accounting rules for the financial statements of public companies
Ensures consistency, transparency and ability to compare

141
Q

What is the role of the auditor in accounting?

A

The auditor verifies the accuracy of financial statements and tax filings to ensure accuracy.

142
Q

Can you provide an example of carrying out accounting principles?

A

I have requested and provided credit checks of potential contractors for the Employers review however I understand that I am not competent in advising on this and so solely provided the information.

143
Q

Can you advise on the structure of your business?

A

We have recently become an Employee Owned Trust and so is structured by the

Employees & trust consisting of 2 employees, 2 directors, and one independent

Group Holdings - Exec board still make day to day decisions

Independent companies i.e. RPP / RPPML / RPP Asbestos

more collaborative, indirect ownership, beneficiary of annual tax free bonus’ - gov scheme

144
Q

What is working capital?

A

The difference between assets and liabilities

145
Q

What are assets and liabilities

A

Assets = item owned that has value
Liability = item owned that creates money owed

146
Q

What is forecasting in business planning?

A

Forecasting is essential to allow consideration of what will happen in the future and allows business plans to be updated accordingly

147
Q

What is investment?

A

Investment - committing resources to achieve benefits - can be financial or other forms such as training;

Financial - loans, grants
Other - training, resourcing, development

Business plan identifies requirements

148
Q

What is joint ownership?

A

Where a business is owned by multiple partners / organizations
dependent on the business type i.e. directors/ stakeholders etc.

149
Q

What are KPI’s?

A

Key Performance Indicators
quantifiable measures of performance over a time period
Highlight specific objectives
Assist a business in tracking progress against objectives

150
Q

What is net profit?

A

Total after deducting operating costs, interest and tax expenses from growth profit

151
Q

What is PESTLE?

A

form of business analysis based on external factors;
Political
Economic
Social
Technological
Legal
Environmental

152
Q

What is a USP?

A

Unique Selling Point - defines how a business differentiates itself from competitors

153
Q

What are Building Regulations?

A

Provide minimum standards for the design, construction and alteration of buildings.

154
Q

How do different forms of contract deal with dispute resolution?

A

Majority of JCT contracts make provision for mediation, adjudication or arbitration.

Adjudication is a statutory right and so if one party calls on this, the other must concur.

Negotiation is an optional provision under supplemental provisions.
It is also RPP standard to omit the clause for arbitration so it does not apply.

155
Q

What is arbitration?

A

Form of dispute resolution where the proceedings are private and does not go to court. The decision of the arbitrator (private tribunal) is binding. Information is required to be presented in a specific format for the arbitrator to review.
If arbitration applies, cannot go to litigation and difficult to appeal as court typically agrees with arbitrator.

156
Q

What is negotiation?

A

The process is voluntary and non-binding by attempting to reach agreement without the assistance of a third party.
The most informal method of ADR where parties discuss the issue rather than undertaking formal court proceedings.

157
Q

What is mediation?

A

Mediation is a formal process facilitated by a impartial third person. Parties can withdraw at any time and is not binding.

158
Q

What is adjudication?

A

Adjudication is a statutory right under the Construction Act and can be called on by either party and the other must concur. A court judge resolves the issue between two parties and is binding, unless a party refers to litigation.

159
Q

What is litigation?

A

Litigation is similar to adjudication where parties resolve the dispute in court and the decision is binding, but in this instance is binding and final.

Expensive and time consuming

160
Q

What is expert determination?

A

Parties agree to an expert third party to review the dispute, whose decision is binding and cannot be appealed. This is a cheaper option than court proceedings. The decision can only be overturned by going to court.

161
Q

How do you avoid conflict?

A

Good management, record keeping, maintaining professional relationships, good contract documents outlining responsibilities and scope clearly

162
Q

What is the purpose of the final account ?

A

Opportunity to review the full scope and cost of the works where items may not have been recovered during interim valuations. JCT provides an allowance of time for the Contractor to submit the information for the FA to be reviewed (3 months)

163
Q

What is negligence?

A

A breach of the duty of care owed.
Must consider whether a party has been negligent when considering dispute resolution.

164
Q

What is ADR?

A

Alternative Dispute Resolution

165
Q

What is data management?

A

The process of collecting, storing and using data

166
Q

How do you analyse and adjust cost data?

A

When using cost data, I would make any adjustments necessary based on the external factors such as date or location. To do so I would use the project costs on BCIS or adjust my own data using the indices such as TPI. For example, if using a tendered scheme from 2021 to analyse against a tender received in 2023, I would adjust the tender received in 2021 by the TPI.

167
Q

How do you adjust cost using TPI?

A

Tender Price Indices

Cost A/Cost B = Index at Time A/Index at Time B

168
Q

How are team members selected / appointed?

A

Consultants are generally appointed based on past experience with a Client or through recommendation. Alternatively, they may be appointed through a framework.
Team members should be appointed based on merit.

169
Q

Give an example of formal communication

A

All formal communication should be written such as through letters or emails. Another example includes issuing minutes/ records of conversations.

170
Q

Give an example of informal communication

A

Via verbal conversations

171
Q

Give an example of inclusive communication

A

A forum for all those relevant to communicate. For example, a teams site for all parties on a project to communicate.

172
Q

Can you advise on your internal diversity and inclusion policies?

A

RPP have a diversity and equality policy which commits to eliminating discrimination. All employees should be treated fairly by all other employees and should provide fairness within the workplace.

173
Q

Can you explain what unconscious bias is and your understanding of it?

A

I understand unconscious bias to be where an individual makes judgements or decisions based on deep rooted patterns and so are not aware they are doing it. This is often judgments based on stereotypes such as race, age, gender or other factors.

174
Q

How would you tackle unconscious bias?

A

It is important to highlight any unconscious bias if spotted through reporting behavior or discussing this. It is important to educate yourself but also propose training if it is deemed required in the workplace.

175
Q

How does inclusivity and diversity benefit businesses?

A

Inclusivity and diversity help with innovation and creativity. In addition, it creates an environment where employees may feel more comfortable.

176
Q

What do you understand of inclusive environments?

A

Creating a space that is accommodating to all.
Environment where not discriminated against.

The critical item is to create spaces in accordance with the minimum standards set out in Approved Document M but also further this through other provisions that may create more inclusive spaces.

177
Q

Can you provide an example of ethical inclusive environments rather than legal?

A

When visiting a SEND school which will be the next Big Build project, it was clear that the existing structure met building regulations for access and use however was not suitable for the students using the space such as poor ventilation and small spaces.

178
Q

How do sustainable regulations affect construction?

A

The revised Part L (conservation of fuel and power) means that the standards for construction have improved where buildings must reduce their carbon emissions compared to previous standards. This means that more sustainable materials and technologies must be used.
May increase the cost of construction in some areas or impact the programme due to long lead items.

179
Q

Can you advise on some design considerations/ options for reducing carbon or improving sustainability

A

Low carbon materials in construction i.e. prefabricated steel reduces transport, timber, green roof, installation of PV or heat pumps, sourcing of local materials, smart technology in M&E controls, options such as removing ceiling finishes and exposing M&E - BMW & Wellington Place

180
Q

Can you provide sources of renewable energy

A

PV panels, solar farms, wind energy, hydrogen, green steel (made using renewable energy),

181
Q

How much does the built environment contribute to UK Greenhouse Gas?

A

42%

182
Q

How does property impact the environment?

A

The goal is to become net-zero by 2050.
80% of 2050 building stock already built (UKGBC)
Industry contributes to 42% of GHG emissions
Critical that Built Environment reduces carbon & assists in retrofitting existing.

183
Q

What information is contained within a client brief?

A

Identifies the Clients requirements - Document which develops as the project progresses

184
Q

What is included within an appointment?

A

The appointment
scope of service
limitations of liabilities
collateral warranties
clients obligations
payment terms
insurance
termination/dispute
fees
services
H&S
Adjustment to the fee/ additional services

185
Q

How would you proceed if you received a complaint?

A

If verbally, I would initially ask that this be made in writing
Once in writing, I would confirm receipt of the complaint by response and advise this will be passed onto a senior colleague for review and action.
pass the information onto the relevant colleague as identified within the complaints handling procedure
Highlight that a response is required within 28 days and that our PI insurers must be made aware.

186
Q

How do you ensure communication is formal?

A

Ensure in writing
any communication is professional
be mindful that in writing it may be kept as a record and emails can be viewed as contracts/ instructions in court

187
Q

How would you keep record of important information that benefits client care?

A

store information as per my company’s filing system
ensure any emails/ information that may be called upon is saved in the relevant place
For QA purposes, ensure a copy of our appointment is in the relevant folder.

188
Q

When issuing a report to a new client, how would you proceed?

A

Ask if there is a specific format the Client would prefer me to use, for example one of my clients has their own cost report that the QS’ must populate.

If that is not the case, I would use an RPP template to ensure consistency.

189
Q

When presenting a report, how do you ensure this is delivered competently to the Client

A

Provide a copy for their review prior to the meeting
Present the report in a professional manner, ensuring to provide the information relevant to support the report and presentation
Ensure any questions can be asked at any point to avoid confusion
Ask whether anything needs to be reviewed in more detail and that everything is understood

190
Q

Provide an example of where you issued an estimate/cost plan to the Client and this was reviewed further/analysed?

A

On the residential scheme in Harrogate, I issued a cost plan to the Client and arranged a meeting to review this. During this meeting, the Client queried the rates and items included such as the cost difference between stone and brick. I provided evidence of the cost data source and discussed this to support the inclusions.

191
Q

Provide evidence of where you have advised on different design solutions

A
  • prefabricated valet bays at Mini
  • change to the stairwell lock system at Pannal
  • design solution to visible ductwork where was below ceiling grid - cupboard
192
Q

Please provide an example of where you have advised a client where materials have had a significant impact on cost.

A
  • Pannal - noted the specification of the stone was expensive and other solutions could be reviewed to value engineer the scheme; changed to a cheaper spec
  • Pannal - specification of the kitchen fit out
  • BMW - option of installing rooflights following installation of the roof, provided costs for that and alternate cheaper options to gain daylight; windows cut into cladding
193
Q

What documents are included within contract documents?

A

JCT Contract
Preliminaries
Preambles
Outline spec
Pricing document/ provisional sums
Drawings
PCI
Drawings
Specification
Amendments
Any site information/ investigations
Planning

194
Q

What documents are included within tender documents

A

Invitation to tender
Preliminaries
Preambles
Outline spec
Pricing document/ provisional sums
Form of tender
Drawings
PCI
Drawings
Specification
Amendments
Any site information/ investigations
Planning

195
Q

Why is it important to include the planning conditions/ consent within tender pack

A

May include information not expressly included within the tender information i.e. working hours and constraints
will advise the contractor of conditions that have to be met

196
Q

What are third party rights

A

Provides power to a third party to enforce the terms of a contract

Third party rights under JCT = able to benefit - contractor is liable to that party, access to design documents, liability is proportionate to third parties loss, C must give notice to third party if wishes to terminate, materials are in accordance with contract.

197
Q

What are collateral warranties?

A

Collateral warranties are a supporting document to the main contract that provide a contractual link between the client and other parties i.e. sub-contractors and consultants

198
Q

What sub-contractor warranties are required?

A

All those with a design responsibility

199
Q

What is acceleration?

A

Where the Employer wishes to advance the practical completion date so the works complete earlier than the contract completion date.

200
Q

How is acceleration achieved if requested by E

A

E issues invitation for Contractors proposals to achieve this
C provides an acceleration quotation (open for 7 days)
If E accepts: Contract sum adjusted accordingly & dates revised
If E declines: cost must be included for time to prepare quotation

OR C advises it is not achievable but must present why

201
Q

How is an extension of time claim reviewed?

A

C submits EoT claim
EoT claim should demonstrate the delay as a result of a relevant event and provide details including the duration of the delay and impact on the programme.
CA reviews EoT claim
EoT either denied or granted

202
Q

Difference between relevant event and relevant matter

A

Relevant Matter = Client is responsible & entitles C to loss/expense
Relevant Event = Caused by client or is a neutral event - does not necessarily entitle to L/E

Both cause delay to completion date

203
Q

What is a Letter of Intent

A

Expresses an interest on the part of a party to enter into a formal contract, as per the details contained in the LOI.

Programme dates
contract sum
Contract contents
payment terms
Authorised work & Maximum amount
Termination terms

Will often specify only orders can be placed for certain packages, based on long lead times, or only certain elements can be complete under the maximum amount

204
Q

What happens when the contract is issued, following the LOI?

A

The contract supersedes the Letter of Intent

205
Q

How would you manage the tender opening process if a Contractor issued their tender early?

A

I would wait until the specified time on the form of tender to open all tender returns at the same time.

206
Q

How would you manage a tender process if a Contractor returned their tender late?

A

Late tenders should certainly not be
considered for public procurement projects. Private clients should be advised which tenders were late and if they wish them to still be considered then they must
provide explicit instruction to do so.

207
Q

How would you deal with errors within the pricing document?

A

Provide the opportunity for the Contractor to review the costs for the item and either adjust or stand by

208
Q

What is your understanding of the rules of tendering in public procurement?

A

Although I have not carried out works in the public sector, I do understand that the tender must be carried out in line with the UK Public procurement policy and
- contractors must be aware of how the tenders will be evaluated
- the process must be fair with the contractor appointed based on the evaluation criteria
- all deadlines must be clearly stated
- undertaken via a open process.

209
Q

When would you use an NEC contract?

A

Although I have not used NEC, I would expect the contract to be used on an engineering project. However, they can also be used on construction projects where the works are of a large nature.

210
Q

Which contracts are EA/CA used on?

A

EA = D&B
CA = Traditional

211
Q

How do you ensure effective cost control during a project?

A

On a scheme on an ICD contract, I ensure to review any updated drawings and highlight any changes that may have an impact on cost.
Following this, if the Contractor has not provided a cost for this element, I include an estimated cost within my cost report to identify any anticipated increases to the Client.

212
Q

How do changes to Building Regulations effect the cost of construction projects?

A

New regulations are likely to request higher standards of building
i.e. Part L now requires lower carbon emissions in buildings. This is likely to have an impact on cost where higher specifications are now required and therefore existing cost data may not be comparable.

213
Q

How do you manage risk in a cost plan/report?

A

Review the information available and identify the main risks based on the different types i.e. design development, construction, employer changes or other.

For example, if the design was not detailed, I would include an allowance for design development. Or, if there was no site investigations carried out, I would now include an allowance for unforeseen ground conditions/ additional works required.

Reduce risk allowance when design/ information develops

214
Q

How do you value change?

A

I would carry this out in line with the valuation rules. For example, the valuation of additional works shall be consistent with that in the CSA and likewise for the omission. Any valuations must also include allowances/reductions for preliminaries.

215
Q

How would you manage a change request?

A

Where the change requested by the employer: -
- Request a cost from the Contractor
- Provide the cost to the Employer for approval
- If approved, issue an instruction and request the update of any drawings relevant

Make clear during the pre-start that no changes should be carried out without instruction from the CA/ EA.

Where a change proposed by the Contractor:
- Obtain the proposal from the C showing any programme / cost impact/saving
- Issue to the Employer and provide any supporting information
- If approved, issue an instruction
- If not, advise C to proceed as per the contract documentation

216
Q

Can you give an example of the change control procedures you have put in place?

A

On a Design and Build scheme where the novated architect had a working relationship with the end-user, I clarified that there should be no updates to the drawings that would constitute a change under Clause 5.1, without a formal instruction issued by myself.

I advised the Contractor to make myself aware of any changes that they would deem a variation, and to obtain approval prior to proceeding.

On a traditional scheme, I reviewed the drawings issued by the design team and identified any changes with a cost or programme impact. I included allowances for these items within my cost report where the costs were not yet agreed so as to highlight any forecasted expenditure.

On all projects I aim to agree all variations throughout the project duration as best practice to assist in the final account negotiations.

217
Q

Can you give an example of where you have reviewed a programme for construction works?

A

On a new-build school facility, the contractor issued their revised programme which amended the sequencing of the works, but still met the completion date. Following a review, I noted that a number of the activities had reduced in length by significant amounts.

I therefore queried this with the Contractor to understand how the periods had reduced and whether there was any risk to the programme.
I advised the Client of this and was mindful during valuations and progress meetings to query any programme concerns.

218
Q

Can you give an example of where you have reviewed payments?

A

BMW Crewe
Reviewed invoices on a monthly basis to ensure these were as agreed and in line with the approved quotations

Review valuations against the programme and cashflow

219
Q

How do you analyse project risk?

A

Review information
Organise risk workshop with design team and potentially contractor
Compile risk register
All parties contribute to highlight key risks
Identify likelihood and severity of risk
Identify largest risks
Monitor throughout scheme

220
Q

What should be included on a risk register?

A

Event
Likelihood 1-5
Impact 1-5
Multiply likelihood by impact
Risk from 1 being low to 5 being high
Those with highest scoring to be monitored in more detail
Mitigation strategies identified

221
Q

How is the level of contingency determined?

A

Based on risks and unknown specifics.
Less design = higher contingency

222
Q

What do TPI’s show?

A

Reflect changes in the level of tender prices over a period of time. Consider levels of inflation.

223
Q

What is the base date?

A

The date in which the cost information is based on.

Base date in tender documents = 10 days prior to tender returns.

224
Q

What is value?

A

Benefit derived from a course of action and the cost/effort required to achieve it.

Measure of worth considering usefulness and benefits that are delivered in comparison to cost

225
Q

What are life cycle costs?

A

Costs incurred over a defined period of constructing, operating and maintaining a building through to end of life i.e. demolition.

226
Q

What costs are considered in life cycle costing?

A

Capital costs/ operational/ maintenance

227
Q

Is it realistic to cashflow a scheme based on contract sum/ length of programme.

A

No, a cashflow should be calculated using the programme and schedule of activities against the pricing document. A sum/ week would be unrealistic. An accurate cashflow should show an S curve- lower costs at the start, increase through middle stages and level out towards end

Example - BGS cashflow calculated using work schedules and programme of activities

228
Q

How should you issue an instruction?

A

An instruction should be in writing using a consistent format, noting the date, change, impact on cost and any programme impact.

Instructions can be issued with approximate costs/quants or costs TBA but for ease at FA, these should be agreed where possible.

229
Q

Can you issue verbal instructions?

A

Verbal instructions can be issued but must be followed up in writing within 7 days otherwise they are of no effect.

230
Q

How would you obtain costs for an instruction/ variation under JCT Contract?

A

I would request a Schedule 2 quotation from the Contractor to include a quotation or a schedule of rates.
Alternatively, I would undertake a valuation of the works under the valuation rules and agree this.

231
Q

What do you understand to be Loss and Expense?

A

Loss and Expense reimburses contractor for costs incurred in carrying out additional works or as a result of E breach.

232
Q

If you cannot agree on something with a contractors QS, how would you proceed?

A

Aim to resolve all issues through negotiation
Discuss the issue and positions with a senior colleague and/or the Client
Attempt to negotiate and agree a revised position with the QS.
if cannot, I would refer to further ADR options as identified in the Contract.

Example: BMW Crewe FA - negotiate all items but those cannot agree in principle, discuss with Client to understand their position and negotiate overall cost and bottom line to meet an amenable FA for all.

233
Q

What are the 5 relevant matters?

A

Variations
Instructions
Adjustment of approx quant
Suspension for non-payment by E
default/ impediment caused by E

234
Q

What are dayworks?

A

Although I have not undertaken a project where dayworks have been accepted, I understand that…

Dayworks are the prime cost of materials, labour and plant used to carry out works, along with % additions listed in contract.

The daywork schedules are provided and signed off by the CA/EA and cannot be adjusted by the QS once approved.

235
Q

How are loss and expense claims claimed/analysed?

A

C must notify the CA as soon as it becomes apparent that L/E may be incurred - in writing.
C should submit any further information requested to support this along with value.
QS should then review this to confirm the value is the actual loss incurred.

236
Q

What can be expected to be claimed for in Loss/Expense?

A

Prolongation
Additional preliminaries
Disruption
Overheards
loss of profit
claim preparation costs

237
Q

How would you measure a basement?

A

I would review the drawings to confirm the construction.
Referto NRM1 for build up

On a residential scheme, the basement was piled and so;
Excavation & disposal
Piles to wall
Prep of excavated surface
Waterproofing
Blinding
Formwork
Concrete to walls and slab
Reinforcement
Finishes

238
Q

How do you ascertain the volume of material to be disposed?

A

I would assume the volume to be the same as that excavated, unless the drawing identified any backfill areas.

239
Q

What is substructure and superstructure

A

Substructure - below DPC
Superstructure - above DPC

240
Q

What is the purpose of a site investigation?

A

Collect and record data to assist the design and construction of a project.

Includes:
Existing trees, existing services, ground water conditions, soil investigations, trial pits

241
Q

What are the main site considerations?

A

Access, temporary services, storage, plant, fencing and hoarding, health and safety risks

242
Q

What is scaffolding?

A

Temporary works structure to assist working at height due to H&S

242
Q

What are pile foundations?

A

Series of columns inserted into the ground to transmit the load to a lower level of subsoil
Used where high water table/poor ground

242
Q

What are temporary works?

A

Structures built for the main construction works to commence.
May be required as a result of health and safety
I.e. scaffold

Example: Construction of a retaining wall left steep banking. PD advised that weights should be added to the fencing to prevent falling into excavation as on school grounds - H&S risk.

242
Q

What is shoring?

A

Temporary support given to existing buildings to avoid collapse.

242
Q

What is a borehole?

A

Used for site investigations, especially where deep foundations required

243
Q

What is a retaining wall?

A

A structure used to retain soils.

243
Q

Can you advise on the advantages/ disadvantages of a steel frame?

A

Quicker to construct, recyclable, not vulnerable to termites, consistent quality, strict QM controls, non-combustible, cheaper foundation solution.

Fire protection to be added retrospectively
Steel price fluctuates so less certainty
Require skilled labour to install

244
Q

can you advise on the advantages/disadvantages of a concrete frame?

A

Fire protection is part of the structure, lower maintenance requirements, good sound and heat properties, cost certainty as fluctuates less

More time consuming to install, more expensive, heavier so requires larger foundations = cost increase

245
Q

Can you advise on flat roof construction?

A

On a recent job, a bauder solution was reviewed which included
Ceiling
Joists
deck
Air and Vapour control layer
Insulation
Underlayer
Cap sheet

246
Q

What is the difference between a warm and cold flat roof?

A

Warm = insulation above the joists
Cold = Insulation between the joists

Recent flat roof = cold roof construction

247
Q

Can you list some common components you would expect to find in a steel frame construction?

A

Beams
Columns
Purlins
Rafters
Eaves
Base Plate
Cladding rails
Cross bracing
Fixings

Beam = flange, web root

248
Q

What is a powder coating?

A

Coloured coating applied on metals
Should be carried out after any holes/cutting to coat entire surface

more durable than paint

249
Q

What is RHS and SHS

A

Rectangular Hollow Section
Square Hollow Section

250
Q

What is intumescent paint?

A

Fire protective paint often used to protect steel.
Stops oxygen reaching material.
Should be applied in factory

251
Q

What is formwork?

A

Temporary works to hold fresh in-situ concrete until it hardens/sets.

252
Q

How would you proceed if a client advised of including LAD’s at £100,000 per week?

A

I would advise the Client that LAD’s must be a genuine pre-estimate of loss and to provide further information to support this figure.
I would note that this figure must be supported and should not be included unless could be justified during ADR proceedings.

253
Q

What must be in place for the Client to deduct LAD’s

A

Under JCT D&B/ICD :
Non-completion certificate
Notice to state they will be deducting/ withholding damages

Under MWD:
Notice to state they will be deducting/ withholding damages

254
Q

What do you understand as time at large?

A

Time at large is where there is no set completion date.
The contractor does not have to proceed within a reasonable time as no date set.
Damages cannot be claimed as there is no date to deduct from
E must prove C did not complete in a reasonable time

255
Q

How would you explore the ability to achieve acceleration?

A
  • extending working hours
  • sequence of works
  • increase resources
  • incentives

Obtain quote from C for E approval
Cost to provide quote must be paid if quote rejected

256
Q

When would you advise that the works are practically complete?

A

PC is not defined within the JCT Contracts however I understand this is the CA/EA’s responsibility to define and so I view PC as:

When the works are substantially complete except for minor snags and outstanding works.
E must be able to occupy the building

257
Q

How does issuing practical completion impact contractual mechanisms?

A

Half of the retention is released
E cannot deduct LAD’s beyond this date
E insures the building and takes possession
Rectification period begins

258
Q

What would you ensure is agreed when issuing partial possession?

A

The extent of the area of the works to be taken, the date, consent from the contractor.

259
Q

What is the difference between partial possession and sectional completion?

A

Sectional completion is the pre-agreed contractual right for the Employer to take possession of the pre-agreed area/works.

Early/partial possession relies on the contractors consent.

260
Q

What is assignment?

A

Rights and benefits of one party transferred to another

261
Q

What would you advise the Employer if they queried risk with novation?

A

That novation removes the right to take action if the party for a breach and so a collateral warranty should be put in place.

262
Q

What is a bond?

A

Guarantee from a surety (bank) to ensure the contractual obligations will be fulfilled.

Does not guarantee completion, but will provide monies of a certain value for E to complete (usually 10% of contract sum)

263
Q

What is a parent company guarantee>

A

Guarantee from the corporate group, of which the C is part of, will fulfill obligations or pay the financial equivalent.

264
Q

How would you advise a client to proceed if a Contractor failed in their obligations?

A

Have not experienced this but…
Initially discuss with C to identify issue and try resolve
Failing this,
Review contract mechanisms - Refer to section 8 - termination.
Issue a notice to identify failure
Follow contract mechanisms to terminate contract
Seek legal advise
If relevant, Call on the bond / parent company guarantee

265
Q

What is the difference between on-demand or conditional bonds?

A

On-demand - E can call upon the bond without having to satisfy / review conditions to demonstrate default
Conditional - E must meet conditions that set out the evidence of default

266
Q

What is insurance?

A

Transfer of a defined risk to an insurance company in exchange for a premium

267
Q

When should an LOI be used?

A

Where an early start on site is required
Instruct initial works
Where discussing main contract

268
Q

What is procurement?

A

Act of obtaining goods/services

269
Q

What is submitted at the first phase of two stage tendering?

A

Preliminaries
OHP %
Schedule of rates to proceed with when agreeing overall cost
Price for design development
CP’s

270
Q

What are contractors proposals?

A

Contractors response to ER’s
Key document to review
Plans/ details

271
Q

What would you include in a pre-qualification questionnaire?

A

Have not used one however understand;

  • contract particulars
  • company turnover
  • relevant experience / references
  • organisational structure
  • H&S
  • Quality Management processes
  • Provision on bonds/ insurances/warranties
272
Q

How would you advise on the tender period?

A

It would be determined based on the complexity, size and procurement process.

For example, a simple scheme may only require 2-3 weeks
In order to obtain accurate tenders, a longer period may be required for a D&B complex project.

Pannal - D&B, two schemes under one contract so complex phasing etc. Offered 6 week period with 1 week extension

273
Q

What is a BMS?

A

Building Management System
BMS are computer based systems used to control and monitor building services
Can optimise buildings performance, give better control, gather data, report, improve safety

274
Q

What is the difference between Value Management and Value Engineering?

A

Value Engineering = process of removing cost without impacting function

Value Management = Process of maximising value by defining scope and requirements at early stages

275
Q

What are the different types of RICS Documents

A

The most important ones include professional statements, code of practice and guidance notes.

The professional statements are mandatory, code of practices may sometimes be mandatory and is defined on the document whether as guidance notes highlight best practice.

276
Q

What is an advance payment bond?

A

Surety product that protects money been provided to the contractor, by the employer

277
Q

What is an advance payment?

A

Process of E providing money upfront to the Contractor prior to receiving the goods/ services under the contract.

278
Q

How would you ensure costs are fair/reasonable/competitive when carrying out a two stage tender?

A

I would ensure to obtain multiple quotations for the packages to ensure the costs are competitive and represent the current market.

279
Q

What is run-off cover?

A

Runoff cover is the professional indemnity cover for employees that no longer work for the firm - as a minimum of 6 years.

280
Q

What is benchmarking

A

The process of collecting/ comparing data to identify the best in class

281
Q

How does the JCT deal with inflation?

A

Fluctuation provisions

Option A: Contribution, levy and tax i.e. tax on imported goods
Option B: Fluctuations in labour and material costs i.e. adjustments to costs at base date
Option C: Adjustment using the JCT Formula rules