Brainscape's Knowledge GenomeTM

Browse over 1 million classes created by top students, professors, publishers, and experts.


See full index

WS - APC Technical Competencies > Contract Practice > Flashcards

Contract Practice Flashcards

1
Q

What is included within the contract documents for a project?

A
  • Building Contract, Articles of Agreement
  • Schedule of Amendments
  • Design / Drawings
  • Employer’s Requirements / Contractor’s Proposals (if relevant – D&B/CDP)
  • Contract Sum Analysis
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
2
Q

Who are the key parties involved in construction contracts?

A

Employer
Contractor
Contract Administrator (Standard Building Contract)
- Expected to maintain impartiality whilst administering
- Contractor must comply with their instructions
Employer’s Agent (Design and Build Contract)
- Contractor must comply with their instructions
Quantity Surveyor
- SBC: Party to the contract
- DB: Not party to the contract but expected to maintain impartiality if involved in administering/

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
3
Q

What is the role of the QS in construction contracts?

A
  • Value variations
  • Ascertain loss and/or expense
  • Carry out interim valuations
  • Prepare the final account
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
4
Q

What is the Contractor’s obligations in construction contracts?

A

The contractors obligations are identified in clause 2.2 of the JCT SBC and clause 2.1 of the JCT DB contract.

  1. Complete and carry out the works in a proper and workmanlike manner
  2. All materials and goods are of the standard described in the specification / Employer’s Requirements.
  3. Give all notices required by the Statutory Requirements and comply.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
5
Q

What is the clients obligations in construction contracts?

A
  • Payment of the contractor on time
  • Do not disturb the contractor from working with reasonable skill and care.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
6
Q

What are the five key elements for contract formation?

A
  1. Offer
  2. Acceptance
  3. Consideration
  4. Capacity & Competence
  5. Intention to Create Legal Relations
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
7
Q

How are construction contracts executed and what are the main differences?

A
  • A contract can be executed as a deed or under hand.
  • The principle difference is the party’s liability period for breach of contract.
  • 12 years if executed as a deed, 6 years if executed under hand.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
8
Q

What is a standard form of contract?

A
  • Set of formal, pre-determined arrangements and mechanisms that form the basis of agreement between parties.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
9
Q

What are the typical amendments made to standard forms of contract?

A
  • Transfer risk to the contractor by reducing the list of relevant events / matters
  • Final date for payment due to contractor lengthened, from 14 to 28.
  • Rectification Period extended from 6 months to 12 months
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
10
Q

What are the types of contract under traditional procurement?

A
  • Lump sum contract, where contractors agree to execute the work for a fixed total sum of money.
  • Re-measurement contract, Where the contract sum is not finalised until after completion but is assessed on re-measurement to a previously agreed basis.
  • Cost Reimbursement Contract, Where the sum is arrived at on the basis of prime costs of labour, plant and materials to which there is an added amount of OHP.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
11
Q

What are the types of contract under design & build procurement?

A
  • Turnkey Contract - Client settles on a complete package (ready to move in) to a specification provided by a contractor.
  • Design & build contract - Employer’s requirements will be written stating the Contractor’s design obligations for the whole of the works.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
12
Q

What is the difference between JCT and NEC contracts?

A

NEC references compensation events as events which may entitle a Contractor to claim both additional time and additional costs, whereas ** JCT differentiates Relevant Events and Relevant Matters.**

JCT contains provisional sums whilst the NEC does not.

The Activity Schedule is a key contractual document of the NEC and is to be updated regularly.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
13
Q

When is the JCT SBC used and who is responsible for administrating the contract?

A
  • Designed for use when traditional procurement route has been chosen.
  • CA and QS administer the performance of the contractual obligations.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
14
Q

What are the types of contract under the SBC?

A

Standard Building Contract with Quantities
- Fixed price lump sum contracts with monthly interim payments.

Standard Building Contract without Quantities
- Contract Sum Analysis completed by Contractor defines the work.

Standard Building Contract with Approximate Quantities
- Re-measurement contracts are used in situations where the design/type of works can be described in reasonable detail but the amount cannot be given

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
15
Q

What is a SBC with contractors design portion?

A
  • Option that allows the employer to require the contractor to design discrete parts of the works but not whole majority (otherwise DB might be more appropriate).
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
16
Q

When is the JCT Minor Works contract used and who is responsible for administrating the contract?

A
  • Designed for use when traditional procurement route has been chosen.
  • Used on smaller, lower value, more basic, shorter programme construction projects.
  • Architect/CA and QS administer the performance of the contractual obligations.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
17
Q

What are the types of contract under the the Minor Works Contract?

A

Minor Works Building Contract
- Fixed price lump sum contract with interim monthly payments
- Employer must provide a pricing document, drawings and specifications to specify the quantity and quality of work

Minor Works Building Contract with Contractor’s Design
- Employer must detail the requirements for the parts of work that contractor is responsible for designing.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
18
Q

When is the JCT Design & Build contract used and who is responsible for administrating the contract?

A
  • Designed for use when design and build procurement route has been chosen.
  • DB projects can vary in scale but are generally suitable where detailed provisions are needed.
  • The EA administers the performance of the contractual obligations.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
19
Q

What are the Employer’s Requirements in a DB contract?

A
  • Details what the employer requires from the completed project and the required level of design responsibility from the contractor.
  • Scale of design work can vary: contractor may be required to complete the design produced by a design team or they might be required to carry out all of it.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
20
Q

What are the Contractor’s Proposals in a DB contract?

A
  • Design prepared in response to employer’s requirements.
  • Set out their proposals for designing and constructing the project, along with their price.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
21
Q

What is Novation?

A
  • Parties may agree that the design team initially engaged by the employer should be transferred from the employer to contractor to complete the design
  • DB contract will require amendments as the standard contract does not provide provisions for novation.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
22
Q

What are the key differences between standard building contracts and DB contracts?

A
  • Full design at tender stage with a SBC, whereas a DB could range from simple set of ER’s to full design.
  • Client retains control over design in SBC so quality is perceived to be higher.
  • CA in a SBC and EA in DB.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
23
Q

What are the Recitals under JCT contract suites?

A
  • Recitals contextualise the agreement, giving factual explanations for the basis of the contract.
  • The Recitals include:
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
24
Q

What are the Articles under JCT contract suites?

A
  • The Articles set out what is agreed between the parties.
  • The Articles include:
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
25
Q

What are the Contract Particulars under JCT contract suites?

A
  • Sets out the aspects of the contract that are specific to the project.
  • For example the retention, completion dates and insurance requirements.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
26
Q

What are the Attestation under JCT contract suites?

A
  • The attestation is the process of confirming that something is correct or genuine.
  • This is how the contract is executed, either under hand or as a deed.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
27
Q

What are the Supplemental Provisions under JCT contract suites?

A

The Supplemental Provisions ensures the specific project requirements or risks are addressed.

They can include:

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
28
Q

Who is the contract administrator and what is there role?

A
  • Appointed by the Client to act on their behalf and responsible for administering the construction standard contracts.
  • Role can include forming Contract Documents, Managing contract changes and monitoring the progress of works
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
29
Q

Who is the employers agent and what is there role?

A
  • An employers agent acts on behalf of the client as the contract administrator for design & build contracts.
  • Issuing instructions, Managing change control procedures, Reviewing the progress of the works and preparing reports for the client.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
30
Q

What is deferment of possession under SBC clause 2.5?

A
  • Stated in the CPs that the Employer may defer giving possession without the consent of the Contractor.
  • If possession is deferred, the Contractor may claim an EoT and direct loss and/or expense.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
31
Q

What is a letter of intent (LOI)?

A
  • Expression of the intention to enter into a contract at a future date.
  • Does not create a contractual relationship but where there are good reasons to start work in advance of formalising the contract.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
32
Q

What is early use by the employer under SBC clause 2.6?

A
  • Contractual mechanism whereby the Employer may, with the Contractor’s consent, use or occupy the site/part of the site before the date of issue of the Practical Completion.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
33
Q

What is section completion under a SBC?

A
  • Express term of the contract that allows different dates for Practical Completion to allow the Client to take possession of the completed parts of the site whilst construction continues on the others.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
34
Q

What is the difference between partial possession and section completion?

A
  • Sectional Completion is stated in the Contract Particulars however partial possession relies on the contractor’s agreement to allow the employer to take possession.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
35
Q

What is acceleration?

A
  • To increase the planned or current rate of progress in order to complete the project earlier than would otherwise be the case.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
36
Q

What is Extension of Time under SBC clauses 2.27-2.28?

A
  • A mechanism by which a contractor requests a longer period than had been contractually agreed in order to complete the building works.
  • The contractor must give written notice to the CA identifying the relevant event that has caused the delay.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
37
Q

What are the relevant events?

A

Relevant events are events that entitle the contractor to an EOT.

Variations
Instructions
Defermation of possession of site
Exceptionally Adverse weather
Civil commotion
Terrorism and strikes:
Force majeure
Exercise of statutory power

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
38
Q

What is meant by the term ‘Time at Large’?

A
  • Contractor is no longer obligated to complete the works by a particular date.
  • Contractor would be expected to complete the works in a “reasonable timeframe” however what is reasonable is decided on a case by case basis.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
39
Q

What are reasons for ‘Time at Large’ arising?

A
  • Where clauses describing relevant events do not cover all eventualities.
  • For example, Event that is not relevant – miss completion date – time at large – can’t claim LDs as no enforceable completion date.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
40
Q

What is the rectification period?

A
  • Time when the contractor may be recalled to rectify defects which appear following practical completion.
  • Typically 12 months is stated to encounter all seasons. CPs state that 6 months applies if no other length is stated.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
41
Q

What is retention within a contract?

A
  • Percentage of each interim certificate that is deducted to be retained by the employer as a safeguard against defective work or materials provided by the Contractor.
  • Provides an incentive for the contractor to complete the works promptly by ensuring defects is rectified.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
42
Q

What is the standard retention percentage and when is it released?

A
  • Under a SBC and DB contract the retention is 3% unless otherwise stated.
  • Half retention is issued back when a Practical Certificate has been issued.
  • The remainder is released when the rectification period or defects liability period has expired, typically 12 months.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
43
Q

What is the contract sum?

A
  • Price agreed by the Employer to pay the Contractor to carry out the works.
  • Entered into the contract at Article 2.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
44
Q

What is the base date within a contract?

A
  • A ‘base date’ within a contract is a reference date from which changes in conditions can be assessed.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
45
Q

What are stage payments (Alternative A) under DB clause 4.7.1?

A
  • Payment of agreed amounts on agreed dates or milestones.
  • The Work stages will be identified in the Contract Particulars.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
46
Q

What are interim payments (Alternative B) under DB clause 4.7.1?

A
  • Contractor submits an application for payment and the work is valued by the QS based upon the value of work executed by the Contract by that date.
  • This is a Default option (DB). Only option (SBC).
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
47
Q

What are the reasons for interim payment?

A

Under HGCRA 1996 any contract in excess of 45 days is entitled to interim/stage payments.

  • To relieve the Contractor of the burden of financing the whole of the works until completion.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
48
Q

What are the timescales for interim payment?

A
  • under a SBC the Interim Valuation Date is stated in the Contract Particulars.
  • If no date is stated, the first Interim Valuation Date is one month after the Date of Possession
  • Each Interim Valuation Date is the same date in each month or the nearest business day in that month
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
49
Q

What must the contractors payment application include?

A
  • Gross valuation and net valuation
  • Details showing how the sum has been calculated
  • Deduction of retention
  • Deduction of advanced payments
  • Deduction of the sum of previous certificates and any other payments since.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
50
Q

What is an interim valuation?

A
  • Total value of the work executed, materials on site and any other amounts payable under the contract.
  • Made by the QS to provide advice to the certifier (CA/EA) for the issue of interim certificates and payment notices.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
51
Q

Describe the QS assessment process after receiving the contractors interim application?

A
  1. Ascertain works are in accordance with the contract
  2. Make a fair assessment of the value of the works carried out.
  3. Ascertain valuation ensuring any deductions required are accounted for
  4. Check valuation (comp check)
  5. Assemble associated documentation (issue letters for the Employer and Contractor)
  6. Issue recommendation to CA/EA
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
52
Q

When conducting a valuation, what are the key areas that are to be assessed within the application?

A
  • Preliminaries
  • Main contract works
  • Materials on-site
  • Materials off-site
  • Agreed variations
  • Retention
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
53
Q

What is the due date within a contract?

A
  • Due date is the target date by which the QS must make their interim valuation recommendation
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
54
Q

What is the interim certificate?

A
  • Provides a mechanism for the client to make payments to the contractor before the works are complete.
  • Issued by the CA/EA to both the Contractor and Employer and QS. Must be issued within 5 calendar days from the due date.
How well did you know this?
1
Not at all
2
3
4
5
Perfectly
55
Q

What is the final date for payment?

A
  • Date by which the Employer must pay the Contractor the amount stated in the Interim Certificate.
  • The period of 14 days from the due date for the final date for payment can be amended. This is because it is prescribed by the Contract and not by statute.
56
Q

What is a pay less notice and when might it be issued?

A
  • A method of notifying the other party that they intend to pay less than the sum stated on the interim certificate or interim payment notice.
  • can arise if works have not been constructed in accordance with the contract.
57
Q

What are the valuation rules within a contract?

A
  • Valuation rules apply to all works instructed by the CA/EA, all variations and any expenditure of provisional sums
  • Works can either be valued based on measurable works or day works dependent on the nature of the variation
58
Q

What are the valuation rules for measurable works?

A

There are three rules for measurable work:-

  • If it is of a similar character, quantity and in the same conditions as existing work, then the bill rates should be used.
  • If it is of a similar character, but different quantity or conditions, the bill rates should be used as a basis but a fair allowance should be made to take account of the difference.
  • If it is not of a similar character, fair rates and prices should be used.
59
Q

What are the valuation rules for dayworks?

A
  • Used when variations cannot be valued in another way.
  • Valued based on the prime cost of carrying out the works at the current base date including any additional percentages as identified in the Contract Particulars
60
Q

What is loss and expense?

A
  • L&E reimburses the contractor for direct loss and/or expense incurred in carrying out additional work or from an employer’s breach of contract.
61
Q

What are Relevant Matters under JCT Forms of Contract?

A
  • Events listed in the Contract that entitle the contractor to loss and/or expense
62
Q

What are the relevant matters?

A

A delay that the employer is responsible for and that significantly impacts the progress of the project.
The contractor can claim for any losses or expenses incurred as a result of a relevant matter.

  • Delays in receiving instructions.
  • Instructions relating to variations and expenditure of provisional sums.
  • Discrepancies in the contract documents.
  • Failure to give the contractor access to and from the site.
  • Disruption caused by works being carried out by the client.
63
Q

What are the common heads of claim in loss and expense applications?

A
  • Prolongation.
  • Increasing of preliminaries.
  • Increases in labour or material costs
  • Loss of profit.
64
Q

What is the final account and who is responsible for it?

A
  • Mechanism for the final payment to be made to the contractor on completion of the works described in the contract.
  • Employer’s Quantity Surveyor assesses the final account and recommends a figure to the CA to include within his final certificate.
65
Q

What are the typical headings included in a final account statement?

A
  • Agreed Contract Sum
  • Variable costs i.e. provisional sums, daywork
  • Contract Instructions.
  • Loss and Expense.
  • Risk Allowances.
66
Q

What is a breach of contract?

A
  • If the one of the parties to a contract fails to perform as required by the contract, this may constitute a breach of contract.
67
Q

What are the three types of a breach of contract?

A

Minor Breach = Less serious breach where the innocent party may claim for damages but not consider it is discharged from further obligations under the contract

Material Breach = Serious breach where the innocent party might claim damages and also consider that it is discharged from any further obligation under the contract

Repudiatory Breach = Where one party behaves in such a way that it indicates it no longer intends to accept its obligations under the contract therefore the innocent party can claim damages and terminate the contract

68
Q

What are liquidated Damages (LDs)?

A
  • Genuine pre-estimate of loss suffered by the Employer as a result of non-completion.
69
Q

What are the rules regarding LDs and how are they calculated?

A
  • LD’s cannot be punitive (a penalty to the Contractor), must be a realistic pre-determination of the actual loss the Client is likely to incur.
  • Generally incurred on a daily or weekly basis.
  • QS not qualified or insured to calculate LDs but can inform of what they are and the principles / considerations of their calculation
70
Q

What are the advantages of LDs?

A
  • Limit liability of the Contractor to a known amount and act as an incentive for completion.
71
Q

What are the grounds for termination of a contract by an employer under a SBC?

A

Default by the Contractor = contractor suspends carrying out the works

Insolvency of the Contractor

Corruption of the Contractor = Under Bribery Act 2010, Applies to any Contractor or any person employed by him or on his behalf.

72
Q

What are the grounds for termination of a contract by a contractor under a SBC?

A

Default by Employer = Does not pay amount due (plus VAT) by final date for payment.

Insolvency of the Employer

73
Q

Which insurance provisions are expected under SBC clause 6.4?

A

Public Liability Insurance: Coverage for claims made by third parties for bodily injury or property damage.

Employers’ Liability Insurance: Protection against claims from employees for work-related injuries or illnesses.

Contractor’s All Risks Insurance: Coverage for damage to the works, materials, and equipment on-site, often including theft and accidental damage.

Professional Indemnity Insurance: Depending on the contract, this may cover errors or omissions in professional services.

Insurance for Existing Structures: If applicable, this may cover any existing buildings affected by the project.

The Contractor must, on demand, provide evidence of the policy. Amount is expected to be at least the value of the project

74
Q

Under SBC clause 6.5 what is the insurance of liability of Employer?

A
  • It requires insurance to be arranged, in the joint names of the employer and contractor, to protect the employer from legal liability for injury or property damage – other than damage caused by negligence
  • Cover to protect in the case where the Contractor has taken all reasonable measures to prevent the event from occurring but it does arise.
75
Q

What are the insurance options under SBC clause 6.7?

A

Option A: New Buildings – All Risks Insurance of the Works by Contractor.

Option B: New Buildings – All Risks Insurance of the Works by Employer.

Option C: Refurbishments – Joint Names Insurance by the Employer of Existing Structures and Works in Extensions to them.

C.1 Replacement Schedule

76
Q

Give an example where insurance Option A might be used?

A
  • For use on a new build project where the contractor is required to take out the insurance for the works.
  • E.g. they undertake a lot of construction work and so can add it onto existing policies at a low premium.
77
Q

Give an example where insurance Option B might be used?

A
  • For use on a new build project where the employer elects to take out the insurance for the works.
  • E.g. they undertake a lot of construction work and so can add it onto existing policies at a low premium.
78
Q

Give an example where insurance Option C might be used?

A
  • For use where the construction work is going to take place within an existing structure. This will include fit-out or refurbishment works.
79
Q

Give an example where C1 replacement schedule might be used?

A
  • This would be used when the Employer is the tenant of a landlord and the Landlord takes out the building insurance therefore it is not a simple addition to the Employer’s existing insurance.
  • Usually to state the responsibility is on the Contractor under their public liability insurance.
80
Q

What is professional indemnity insurance under SBC clause 6.15 and why is it required?

A
  • Taken out by anyone providing design and the Contractor if he provides CDP/DB.
  • Various members of design and construction team will have their own insurance policy to indemnify them against liability for professional negligence.
81
Q

What is the joint fire code and when would it apply?

A
  • It applies to mixed-use buildings, new constructions, major renovations, and situations requiring coordinated fire safety measures.
  • The Joint Fire Code (JFC) establishes fire safety standards for buildings with shared occupancy, outlining responsibilities for property owners, managers, and tenants.
  • The JFC ensures compliance with fire detection, suppression systems, and emergency protocols.
  • Not mandatory however is stated within clause 6.17 to state whether or not it applies.
82
Q

What are collateral warranties?

A
  • A collateral warranty creates a contractual relationship where otherwise one would not exist.
  • Provide for a duty of care to be extended by one of the contracting parties to a third party who is not party to the original contract.
83
Q

What are bonds in construction contracts?

A
  • Bonds are a means of protection against the non-performance of the contractor.
  • They are an undertaking by a bondsman or surety to make a payment to the client in the event of non-performance of the contractor.
84
Q

What are on-demand bonds and conditional bonds?

A
  • On-demand bond entitles the beneficiary to call upon the surety for payment whether or not there has been any default by the contractor under the principal contract.
  • Conditional bond is where the employer must prove evidence that Contractor has not performed obligations and that they have suffered a loss as a consequence.
85
Q

what is a performance bond?

A
  • Means of insuring an Employer against the risk of a Contractor failing to fulfil contractual obligations.
  • In the case of Contractor insolvency the bond finances the Employer to re-tender or negotiate to get another Contractor on site.
86
Q

What is a parent company guarantee?

A
  • Provided by a contractor’s parent company in connection with the contractor’s obligations.
  • Can be preferable to performance bond considering there is no additional fee and also the parent company will step in to do the works rather than money and hassle of claims.
87
Q

What is the difference between an EA and CA

A
  • EA in D&B and CA in standard contract.
  • EA represents the employer and manages the overall project.
  • CA focuses on overseeing the contract between the employer and the contractor.
88
Q

What are the different NEC contract options?

A

NEC3 Engineering and Construction Contract (ECC):

Option A: Priced contract with activity schedule
Option B: Priced contract with bill of quantities
Option C: Target contract with activity schedule
Option D: Target contract with bill of quantities

89
Q

What is the difference between Novation and Assignment?

A
  • Novation involves a complete transfer of rights and obligations to a new party.
  • While assignment involves transferring specific rights or benefits to another party while retaining the original party’s contractual obligations.
  • Assignment allows for the sharing of rights between parties.
90
Q

Why did the design team monitor rather than novate to the contractor

A
  • By keeping the design team separate from the contractor through monitoring, rather than novation, maintains their objectivity.
  • Furthermore, this safeguards the client’s interests, and enhances risk management during the design and build process.
91
Q

How can you get a contract signed?

A

Wet signature
- 2016 JCT does not allow for digital signing, unless there is a provision for it.
- 2024 version does allow for digital signing

92
Q

What part of a contract do you sign?

A

The Attestation pages are the area of the Contract where the signatures and details of the individuals who signed the contract can be found.

93
Q

What are some of the conditions in a contract?

A
  • Definitions and interpretation
  • Control of works
  • Payments
  • Changes
  • Insurances
  • Dispute resolution
  • Third party rights
  • Termination
94
Q

What are the schedules included in a JCT contract?

A

6 schedules. DVICTF
Schedule 1: Design submission procedure
Schedule 2: Variations and acceleration quotation procedures
Schedule 3: Insurance options
Schedule 4: Code of practice for opening up of works
Schedule 5: Third party rights
Schedule 6: Forms of bonds, such as advance payment bond and off-site materials bond

95
Q

What are the loss and expense procedures under a JCT?

A

Notify the employer
Provide an assessment
Update the assessment
Keep accurate records

Initial assessment: Within 28 days of receiving the initial assessment and information
Updates: Within 14 days of each update by the contractor

96
Q

How would you included a schedule of amendments into a contract?

A

By appending the the schedule of amendments to the contract, by adding an article.

97
Q

What is the difference between sectional completion and partial possession?

A

Sectional completion is pre-planned and defined in the contract documents.

Typically, if an employer knows in advance that it wants one part of the works finished ahead of the rest, it should provide for sectional completion.

98
Q

What happens after PC cert is issued?

A
  1. Rectification period begins
  2. Half of the retention is released
  3. Insurances are returned to the client
99
Q

What are the insurance options under a JCT?

A

Option A: The contractor takes out joint-names all risks insurance for the works
Option B: The employer takes out joint-names all risks insurance for the works
Option C: The employer takes out joint-names all risks insurance for the works, and the policy also insures the existing structure and contents

100
Q

What are the types of insurance on a construction project?

A
  • Employers’ liability
  • Public liability
  • Non-negligence - 6.5.2
  • Professional indemnity
101
Q

What is Employers Liability?

A

Protects against liabilities to employers for injuries or illness.

102
Q

What is Public Liability?

A

Protects against liabilities for injury to third parties (non-employees) or their property.

103
Q

What is Non-Negligence insurance?

A

6.5.1, gives property owners protection against damage to any property which is not caused by contractor negligence.

104
Q

What is PII?

A

Professional Indemnity Insurance (PII) covers claims made by a client for professional negligence or mistakes made in the work you have done for them.

105
Q

What is a performance bond?

A

A three-way contract between the contractor, the project owner, and a third party, such as a bank or insurance company.

If the contractor fails to meet the agreed-upon performance standards, the project owner can claim on the bond to recover any losses. The guarantor (the bank or insurance company) pays a lump sum to the client, which allows them to finish the project.

Typically 10%

106
Q

What are Third Party Rights in construction?

A

Third-party rights can be used where a collateral warranty will not be issued. They allow someone who is not a signatory to a contract to enforce the benefit of a term contained in the contract.

107
Q

What is the advantages and disadvantages of using an amended contract?

A

Advantages: Tailored to specific deal requirements, mitigate unique risks.
Disadvantages: Time-consuming to draft, higher legal costs, potential for ambiguities.

108
Q

Can liquidated damages be punitive?

A

Liquidated damages are designed to be fair and a genuine cost, rather than punitive.

109
Q

What are the advantages of using a BoQ?

A

Provide a fair and accurate method for tendering contractors to price the project using the same information.
Also can be used as a basis for interim valuations.

110
Q

What are listed items in JCT?

A

Materials, goods, or prefabricated items that are specifically listed by the employer and become the employer’s property when included in an interim payment.

111
Q

Who is responsible for issuing a pay less notice?

A

The employer.

112
Q

What is pricing options A & B under a JCT?

A

Option A: A lump sum contract where the contractor provides a fixed price for the entire project, assuming the risk of cost overruns.

Option B: This option covers changes in the cost of materials, goods, electricity, fuels, or labour. It also covers changes caused by market forces, such as inflation, and supply and demand.

113
Q

What details do you typically include in a LOI?

A

Date of possession
Date of expiry
CSA
Insurance requirements
Intended contract
Employer’s and contractor’s details

114
Q

How is CDP managed?

A
  1. CDP items and ER’s stipulated by design team
  2. Contractor’s Proposals submitted with tender
  3. CPs are reviewed and approval given
  4. Incorporation in to the works / contract
115
Q

What are the main parts of the JCT?

A

Recitals
Articles
Contract Particulars
Attestation
Conditions

116
Q

How can a contract be brought to an end?

A
  1. Expiration: Ends on a fixed date or contract’s termination right.
  2. Termination:
    * Breach: Failure to perform.
    * Anticipatory Breach: Rejecting or disabling performance early.
    * For Breach: Release from obligations due to defective performance.
  3. Vitiation:
    * Misrepresentation: False statement inducing contract.
    * Mistake: Contract void or voidable.
  4. Frustration: Discharged if performance becomes impossible or drastically different.
  5. Damages: Compensation for breach-related loss.
117
Q

Who are the signatories for under hand and a deed?

A

o Under hand – signature of a single Director with one witness
o As a deed – Signature of single director & company secretary / company’s common seal / director with one witness

118
Q

What is Vitiation?

A

Parties have reached an agreement, but question arises over a fact that destroys the basis for which the agreement was reached.
- Misrepresentation – false statement of fact made by one party to another, which induces the other party to enter into the contract.
- Mistake – contract will be void avoidable if a mistake has occurred, so no obligations will arise under it.

119
Q

What are the common types of construction contract?

A

JCT / NEC / ICE / FIDIC
o Joint Contracts Tribunal
o New Engineering Contract
o Institute of Civil Engineers
o International Federation of Consulting Engineers

120
Q

What are articles of agreement?

A

They form the core statement of what the parties have agreed to and include 4 subsections.
o Recitals – explain the facts (works, site, drawings)
o Articles – what has been agreed (contract sum and consultant details)
o Contract particulars – records the variables (retention, possession, completion)
o Attestation – execution (under hand / deed)

121
Q

What are the main differences between D&B and SBC?

A
  • D&B makes no reference to the QS.
  • D&B has and Employer’s Agent, SBC has a Contract Administrator
  • The contractor takes responsibility for design in a D&B (more risk on contractor)
  • Level of design at tender:
    o SBC – full pack
    o D&B – could range from simple set of ER’s to full pack – CP’s as a response.
  • SBC: if contractor misses payment application date, payment certificate date remains.
  • D&B: if contractor misses payment application date, payment certificate date slides back to suit.
  • PI insurance required if the contractor is designing (D&B / CP).
122
Q

Can a collateral warranty be transferred?

A

A CW can be assigned twice without the contractor’s permission. But review is still applicable.

123
Q

What is a disadvantages of a LOI?

A
  • May act as a disincentive to sign final contract.
  • Far less robust than a main contract.
124
Q

What is included in a PCSA

A

o Statement that PCSA does not mean the will enter into the contract.
o Scope of works.
o Cost for scope.
o Programme.

125
Q

Can you name the different types of bonds / guarantees included within the JCT contract?

A
  • Advance payment – Schedule 6
  • Materials off site bond – Schedule 6
  • Retention bond – Schedule 6
  • Performance bond – Clause 7.3
  • PCG – Clause 7.3
126
Q

What are unliquidated damages?

A

Actual damages for a breach of contract, the exact amount of which has not been pre-agreed and is determined by the courts.

  • Employer can claim for unliquidated damages if:
    o Contractor prevents the employer claiming LDs
    o If actual losses are significantly higher than LDs
    o If LDs are not genuine/considered punitive by the court
127
Q

What is a joint names policy?

A

Policy taken out in the names of two or more parties.

It is used to ensure the insurer cannot exercise the right to subrogation against any of the parties’ names on the policy.

128
Q

What are Antiquities and who do they belong to?

A

They are historical artefacts such as bones, fossils or old foundations. Could result in a relevant matter / event.

They belong to the employer.

129
Q

What is the FA cert evidence of?

A
  • All adjustments have been made to the contract sum.
  • Contractor is prevented from seeking to raise any further EoT’s or L&E.
  • Matter has been approved by the CA / EA.
130
Q

What is the FA cert not evidence of?

A
  • That materials or workmanship are in accordance with the contract.
131
Q

What is a certificate of making good?

A

A certificate confirming that all defects have been rectified.

132
Q

What is a fluctuation?

A

A term that describes provisions for dealing with the increase or decrease of cost over a period of time.

133
Q

On what ground can the employer terminate the contract?

A

If the contractor:
o Unreasonably suspends carrying out the works.
o Fails to proceed regularly and diligently with the works.
o Fails to comply with a valid instruction.
o Fails to comply with CDM regulations.
o Becomes insolvent.
o Engages in corrupt practices.
o Assigns the contract or any rights thereunder without consent from the employer.

134
Q

What would be the procedure for termination be?

A
  • The employer shall give notice to the contractor specifying the default.
  • If this default continues for 14 days of receipt of its notice the employer may on, or within 21 days from its expiry by further notice to the contractor terminate their employment under the contract.
135
Q

What must the contractor do after the contract has been terminated?

A
  • Remove temporary buildings, plant etc tat is owned by the contractor from site.
  • Provide employer with copies of all contractor’s design documents.
  • Require the original contractor to assign the benefit of any sub-contracts to the employer.
136
Q

Will any more payment be due to the contractor after termination?

A
  • No further sums shall be due to the contractor.
  • Following completion of the works (by another contractor) within 3 months an account shall be made detailing costs incurred by the employer due to termination.
  • The amount paid to the contractor and total amount that would have been payable under the contract.
  • The balance of this will either become a debt payable to the employer to the contractor or vice versa.
137
Q

Can verbal instructions be given?

A

The JCT contract enables verbal instructions to be issued using confirmation of verbal instructions (CVI’s) under clause 4.3.2 of the JCT contract.
However, it is suggested that all verbal instruction are backed up with a formal written instruction.

WS - APC Technical Competencies (10 decks)

Brainscape helps you reach your goals faster, through stronger study habits.
© 2024 Bold Learning Solutions. Terms and Conditions