Contract Admin Flashcards

1
Q

What is nomination?

A

Selection of a particular subcontractor to carry out works, manufacture or supply of materials.
This provides the architect and client with greater control of material choice and thereby quality.
It is often used when there are long lead-in times with the employer placing orders prior to the Main Contract award which reduces potential delays on site.
The Main Contractor is relieved of liability of design and compliance with the performance spec in addition to subcontractor delays in respect of the works that have been nominated.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
2
Q

Do nominated subcontractors get paid separately?

A

Nominated Contractors are normally paid via the Main Contract with sums identified separately.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
3
Q

Can the contractor object to a nominated subcontractor?

A

Any objections must be made during the tender period.
There are specific exclusions and grounds for an objection for example if they have found out the subcontractor is having financial difficulties and may be going insolvent.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
4
Q

If there are problems with the design, after Novation of the architect, who would be responsible?

A

At the point of novation, the client would agree the level of design was satisfactory & would be signed off by all parties.
The contractor would then become responsible for the Architect & his design should any problems arise during construction.
Disputes may arise where it becomes unclear when problems have arisen, either prior to the transfer of services or afterwards.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
5
Q

What is the difference between Novation and Assignment?

A

Novation is a mechanism whereby one party can transfer all its obligations under a contract and all benefits arising from that contract to a third party.
Assignment is where contractual benefits are assigned however contractual burdens cannot be transferred under assignment.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
6
Q

What is set-off?

A

Set off are any monies owed to the employer by the contractor which are deducted against any payments due to the contractor.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
7
Q

Describe differences between Statutory Provisions and Contract Provisions?

A

Statutory provisions are set out by law & must be complied with.
Contract provisions relate to the contract in question & therefore only apply to a specific project.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
8
Q

What are domestic subcontractors?

A

This is a standard appointment of a Subcontractor by the Main Contractor.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
9
Q

What are named subcontractors?

A

Clients provide the Main Contractor with a choice of named Sub Contractors for a portion of the works.
Once appointed they become a domestic subcontractor in terms of the conditions of contract.
Additional names may be added if approved by all parties.
This allows the client a level of control over the quality of the works packages and in some cases cost.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
10
Q

After valuation and certificate are issued, the client advised that they don’t have sufficient funding to make the payment. What would you do?

A

Once the certificate has been issued to the contractor, the client is contractually obliged to honour payment of the certificate and cannot withhold money without a valid reason.

If this were the case, I would contact the client and contractor ASAP to arrange some form of payment. It may be the case that the client has insufficient funds available in time for the final date for payment and it may be possible to defer payment by 1-2 days.

Failing this or if the contractor is unwilling to delay the payment, the client would need to find finance the payment through other funds to honour the certificate.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
11
Q

What items do you include for on a valuation?

A

Items would include:
1) Prelims.
2) Measured Works.
3) Materials on / off site.
4) Variations.
5) Claims.
6) Retention.
7) Previous payments.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
12
Q

If an instruction was issued during the contract which involved the fabrication of a substantial amount of materials off site would you pay for them as off site materials within the valuation?

A

There is no obligation on the client to pay for materials off site if this is not identified in the contract.
However in the scenario where the client wishes to pay for them, I would ultimately check with the client before paying or rejecting them.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
13
Q

How would you deal with the urgent Verbal Instructions?

A

If the instruction affects the critical path or programme in general I would review the instruction with the contractor administrator, client & contractor.
If the instruction is valid under the contract I would ensure this is converted into a formal written instruction as soon as possible.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
14
Q

What documents would be required in incorporating a Contractor Design Portion Supplement into a project?

A

Within a Design & Build project, the documentation to be included would be the Employers Requirements including the Scope, Specification, Drawings, Contractors Proposals along with any insurances.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
15
Q

Could an e-mail constitute a contract document?

A

Yes providing there is offer, acceptance, intention to create legal relations and the responding email does not vary the conditions, a contract will be created.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
16
Q

What is your opinion of Oral Contracts?

A

Whilst they are legally binding the difficulty lies in proving the specific terms and conditions of the agreement.
It is for this reason why the HGCRA only applies to written contracts.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
17
Q

What is the difference between NEC and JCT?

A

The main difference between the 2 forms is its usage.
NEC can be used within the building & civil engineering projects whereas JCT is specifically for building projects.
NEC can be adopted to a number of bespoke contract strategies due to the various options available whereas JCT has a standard set of clauses.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
18
Q

What is the difference between an information requirement schedule & an information release schedule?

A

The information required schedule asks the Contractor to provide dates when design information is required.

The information release schedule informs the Contractor when the design information will be available.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
19
Q

What is Frustration?

A

Frustration occurs when any event or circumstances beyond control of both parties changes the contractual obligations or makes it impossible or illegal to fulfil their contractual obligations. The happening of such events automatically discharges contract.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
20
Q

How is a contract under hand different from a deed?

A

A Deed is signed by a witness & traditionally authenticated by a seal.
The limitation period of under hand is 6 years whereas a deed is 12 years.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
21
Q

What is the defects liability period?

A

The defects liability period is the duration at the end of the contract, usually 52 weeks after the Substantial Completion Certificate has been issued whereby the contractor undertakes to rectify any defects that arise within the structure at the contractors expense, providing they were due to materials & workmanship not being in accordance with the contract.
In the event that the contractor failed to rectify any defects the employer may employ another contractor to carry out the works & recover the cost of doing so from the Main Contractor.
The retention money retained may be used to cover the costs of making good.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
22
Q

What is your understanding of latent defects and what contractual issues are associated with them?

A

Latent defects are defects which are not readily identifiable upon inspection & only come to fruition some time after building completion and may take many years to become identifiable.
A claim in contract can only be brought about within the limitation period of the contract, 6 or 12 years depending on whether the contract was executed as a deed or underhand.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
23
Q

What should the architect do if they are discovered?

A

The Architect should issue an instruction as necessary to instruct the contractor what to do if they are identified.
This can include telling them to comply with a third party who is examining or opening up the works to identify the defect.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
24
Q

If the works or materials are not in accordance with the Contract what options does the Architect have available to them?

A

The architect may:-
Instruct the contractor to remove all defective work, materials and goods at their own expense and time.
They can notify in writing that they can remain with an appropriate deduction being made from the contract sum.
Issue instructions for variations that are necessary as a result of the work. If they are necessary there should be no additional costs or extension of time given.
Instruct the contractor to open up and test further work to determine the extent of any non- compliance.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
25
Q

When issuing instructions for further opening up and testing to determine the extent of non-compliance what sort of things should the architect consider?

A

The significance of the non-compliance.
Consequences of further non-compliance on building owners and users.
Consequences of further non-compliance on adjoining properties and the public.
Reason for the non-compliance.
Level of supervision and control employed by the contractor.
Currently recognised testing methods.
Time and consequential costs of further opening up.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
26
Q

What is a provisional sum?

A

A sum of money included in the contract for work that cannot be fully designed and costed at the time of tender or contract sum agreement.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
27
Q

What types of provisional sum are there?

A

Defined and undefined

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
28
Q

What is a defined provisional sum?

A

A sum included in the contract for work that has not been completely designed at the time of contract sum agreement but for which certain specified information can be given about the extent of works, its quantity, duration of installation and how it is to be fixed to the building.

How well did you know this?
1
Not at all
2
3
4
5
Perfectly
29
Q

What is the contractor deemed to have allowed on the inclusion of a defined provisional sum?

A

They are deemed to have made proper allowances for carrying out the work in their programme and preliminaries.
This means that they are not entitled to an extension of time or extra prelims for carrying out the work, whatever the delay or cost of doing so to the contractor.

30
Q

What if the actual work does not closely resemble the provisional sum?

A

If the description is not accurate it has to be amended.
This will be treated as a variation.
This will entitle the contractor to an extension of time and extra preliminaries if appropriate.

31
Q

What is an undefined provisional sum?

A

A sum included for work for which there is minimal or no information at the time of contract sum agreement. The location, quantity and time associated for the installation of the works is not fully known.

32
Q

What is the contractor deemed to have allowed?

A

They are not deemed to have allowed for anything.
Expenditure of the undefined provisional sum may carry additional costs for programme or preliminaries as a result of carrying out the works.

33
Q

How can a provisional sum be expended?

A

The architect has to issue an instruction for its expenditure.

34
Q

How are provisional sums dealt with in the final account?

A

The provisional sums included in the contract are deducted and the actual amount substituted.

35
Q

What are the risks associated with provisional sums?

A

The actual cost and time exceeds that allowed for in the provisional sum because the nature of the item changes between tender and instruction.

36
Q

What are the main suites of construction contracts?

A

JCT.
NEC 3 & 4.
ECC.
ICE.
FIDIC.

37
Q

What does ‘JCT’ stand for?

A

Joint Contracts Tribunal.

38
Q

What does NEC stand for?

A

New Engineering Contract.

39
Q

What does ECC stand for?

A

Engineering and Construction Contract.

40
Q

What does FIDIC stand for?

A

Federation internationale des ingenieurs civils.
International Engineers Federation.

41
Q

What does ICE stand for?

A

Institution of Civil Engineers

42
Q

What are the main parts of the JCT contracts?

A

Recitals.
Articles.
Contract Particulars.
Attestation.
Conditions divided into 9 sections (7 for minor works).
Schedules.

43
Q

Name the 9 sections of JCT

A

Definition and interpretation.
Carrying out the works.
Control of the works.
Payment.
Variations.
Injury, damage and insurance.
Assignment, Third Party Rights and collateral Warranties.
Termination.
Settlement of disputes.

44
Q

Name the main types of JCT contract

A

Minor works.
Intermediate.
Standard building contract.
Major Projects.
Design and Build.
Prime cost contract.
Measured Term contract.
Construction Management Agreement.
Management Contract.
Framework Agreement.

45
Q

When would you use JCT Minor Works?

A

Projects that are short in duration on a small scape with a straight forward construction.
JCT guidance is for a value up to £200,000 but it has to be simple in nature.
It is a lump sum form where design should be completed prior to execution.
The Employer or their team is to provide specifications, drawings and a schedule of works.

46
Q

When would you use JCT Intermediate Contract?

A

The Intermediate form is recommended for projects that do not exceed a one year duration.
The project should be simple in content and require only basic skills and trades where services are not complex and where the works are already designed.

47
Q

When would you use a JCT Standard contract with quantities?

A

A JCT Standard Building Contract would be used where the work has already been designed at execution.
It is suitable for use with a bill of quantities and is a lump sum form.
The contractor’s risk is limited to price only.
The employer takes the risk of errors in the bill.

48
Q

When would you use JCT Standard without quantities?

A

This is suitable where work has been designed prior to contract however there is no bill of quantities.
The contract documents will include drawings, specification and a schedule of rates.
It is a lump sum form of contract.
The contractor’s risk includes both price and quantity.

49
Q

When would you use JCT Standard with approximate quantities?

A

This is a remeasurement form of contract.
There is no fixed contract sum.
It is used where the design is not completed at the time of execution.
An approximate bill of quantities will have been prepared.
Construction is aimed to commence prior to the design being completed.

50
Q

When would you use JCT DB?

A

When the contractor is responsible for design and construction.
The project should be similar in complexity to that of standard building contracts.
The contactor’s proposals form the basis of the contract.
There is no mention of an architect or QS instead this role is replaced by the title of Employers Agent.

51
Q

What are the key differences between JCT Minor Works, Intermediate and D&B Contracts?

A

The minor works only has 7 sections of conditions instead of 9. Variations are included within the Control of the Works section and there is no ‘assignment and collateral warranties provision’.
There is no mention of the QS in minor works and D&B however there is in the Intermediate Form.
In Minor Works there is no provision for named sub-contractors, no provision for bonds and collateral warranties and no advance payment provision.
Minor works also has no provision for sectional completion or partial possession.
In Minor Works there are no relevant events listed for extension of time, instead it is referred to as
‘anything outside the contractor’s control’.
The standard rectification period is 3 months for minor works and 6 months for D&B and Intermediate.
The standard retention is 5% for Minor Works and Intermediate and 3% for D&B.
D&B is administered by an Employer’s Agent rather than a Contract Administrator.
In Minor Works and the Intermediate Form, the Contractor may be responsible for completing discrete part of the design whereas in D&B, he is responsible for completing the overall design.

Payments are made at regular intervals in Minor Works and Intermediate Forms whereas D&B gives the option of stage payments.
There is no provision for third party rights in Minor Works or Intermediate Forms.

52
Q

What is a bespoke contract?

A

Contract conditions that are drafted specifically for a particular project.

53
Q

What the advantages of standard forms over bespoke contracts?

A

They are written by legal experts.
Rights and obligations of each party are clearly set out to the required level of detail.
Risks should have been allocated appropriately between the parties.
Parties should be familiar with the provisions in the form providing greater consistency in application and fewer unforeseen anomalies.
The time and expense of preparing a fresh document for each occasion is avoided.
Case law is built up over time and provides a good source of knowledge and clarity of the terms.

54
Q

What are the disadvantages of standard form over bespoke?

A

Apportionment of risks is rarely questioned and therefore becomes implicit meaning it is not reviewed on whether it is appropriate.
They may not be appropriate to the needs of a particular project or client.
Using an inappropriate standard form for the project will cancel out any advantages.

55
Q

When would use a bespoke contract rather than a standard form?

A

They should generally be used for major projects with novel obligations.
When specialist advisors can undertake the amendments as this requires great skill and knowledge.
Drafting from first principles is too daunting for most in the industry.

56
Q

Can you have an EOT without an L&E claim?

A

Yes an EOT does not automatically mean entitlement to L&E.

57
Q

When pricing an EOT what would you include for and what rates?

A

When pricing an EOT I would include costs for prolongation of site cabins, site utilities, welfare facilities, management staff, security, cleaners, inefficient use of labour & plant resources, subcontractor mobilisation costs, head office, finance charges & loss of profit

58
Q

If a project was due to finish before Christmas, but an extension of time was given which meant the contractor finished after Christmas, is the contractor entitled to costs over the Christmas break, which is normally 2 weeks?

A

It would depend on why the EOT had been issued.
The contractor would be entitled to costs over the Christmas period for prelims / site cabins if the reason for the EOT allows the contractor to claim L&E.

59
Q

Would you get involved in helping the Architect assess the Extension of Time?

A

Yes the QS would become involved in assessing the financial implications of the EOT, if applicable.

60
Q

Explain the relative advantages & disadvantages of the NEC and JCT?

A

Advantages of the JCT Suite of Contracts:-
They are considered by many as the “industry standard,” therefore they offer familiarity.
They cover most forms of procurement and building types through the various impressive ancillary documents to support the main forms.
They are comprehensive in detail and considered by many to be fair and reasonable and not loaded in favour of either party.

61
Q

Advantages of the NEC Contract

A

They are applicable to a variety of procurement strategies,
They offer clarity and simplicity by using:-
Ordinary language (minimal legal jargon).
They include flow charts to support their users.
They act as a stimulus to good management through maintaining:-
Up-to-date programmes which are required to be clear and precise.
Provision of early warning procedures and risk registers.
They Embody key features of project partnering.
Assessment of Compensation events by applying a “rolling Final Account.”

62
Q

Disadvantages of the JCT Suite of Contracts

A

They are sometimes though to “compromise conditions,” in which they try to satisfy the interests of all parties.
They can be considered as unnecessarily long and unnecessarily complex.

63
Q

Disadvantages of the NEC Contract

A

They are often only considered to be used for civil engineering projects and partnerships.
They have limited exposure to the market so they are therefore not fully tried and tested with supporting case law.

64
Q

What are the key differences between NEC and JCT?

A

The NEC is concise and written in plain English.
There are a number of optional clauses reducing the need to amend contracts compared to the JCT.
The Project Manager is presented with options to deal with problems as soon as they become apparent.
Provision of early warning procedure and risk register encourage a proactive approach to the management of the project whereas JCT is more reactive.
Compensation events deal with issues affecting both cost and money under NEC whereas under JCT, variations deals with money and loss and expenses deal with time.
Changes are based on quotations prior to commitment whenever possible under a rolling final account under NEC whereas under JCT agreement of costs can be left to the very end of the project.
Cost of compensation events are calculated using schedules of actual costs rather than bill rates under JCT.
There is no QS or Employers Agent mentioned in NEC only a Project Manager who takes on both roles.
The Programme is a contract document under NEC with 25% of money being deducted on interim payments if the contractor does not submit an accepted programme at contract stage.
The NEC has no provision for nomination of sub-contractors but preferred sub-contractors can be listed within the Works Information.
The Defects correction period has different periods specified depending on the impact of the defect under NEC where the contractor must “make good” in these time periods. This approach is much better at dealing with defects when compared to JCT.
Short periods of reply are adopted under NEC which incentivise the parties to respond to each other however is reality the NEC maybe considered as very administration heavy.
Retention and delay damages are optional clauses under NEC.

65
Q

What is a compensation event?

A

Events which, if they do not arise from the fault of the Contractor’s, entitle the Contractor to be compensated for effect on the Prices, Key Dates and Completion Date.
There are 19Nr compensation events listed in clause 60.1

66
Q

What are Early Warning Notices under an NEC contract and what are their purpose?

A

They are notices given by the PM or the contractor of any matter which could potentially have an impact on cost, completion date, key dates or performance of the works in use.
Their purpose is to give the parties sufficient time to consider the options available to prevent or mitigate the issue and collaboratively find the best solution to meet the employer’s interests.

67
Q

How are early warnings dealt with?

A

The PM and contractor have duties to give each other early warnings for inclusion in the risk register as soon as they become aware of an event that may:-
Increase the total of the prices.
Delay Completion.
Delay meeting a Key Date or impair the performance of the works in use.
The PM is to record all the early warnings in the risk register, even if some may not be worth mentioning.
Any party can call for a risk reduction meeting to review the early warning notices and collaboratively find the best solutions to meet the employer’s interests.
As early warnings are resolved, they are removed from the risk register.

68
Q

Name some of the compensation events.

A

There are 19 of them in clause 60.1:-
Changing the works information.
Access to the site.
PM instructs to stop work.
PM or supervisor do not respond to a communication within the timescale stated in the contract.
Object of value or historical interest.
PM withholds an acceptance without valid reason.
Instruction to search.
Adverse weather (as measured in the contract data).
Employer’s risks listed in clause 80.1 and contract data.
PM changes assumptions previously made on compensation events
Employer’s breach of contract.

69
Q

How are compensation events dealt with?

A

The Project Manager notifies the Compensation Event at the time of giving the instruction.
Or the contractor notifies the Project Manager of the CE but he must do so within 8 weeks of becoming aware otherwise they are not allowed compensation.
The PM has one week to decide whether it is a valid CE (or longer if agreed with the contractor).
If the PM fails to do so, the contractor notifies the PM that he needs to make a decision. If the PM still does not respond within 2 weeks of this notification, the CE is deemed to be accepted and the contractor can submit a quotation.
The contractor has 3 weeks to provide a quotation.
Within 2 weeks, the Project Manager can either request a revised quotation, or accept the quotation, or inform the contractor that the proposed change is not being pursued, or inform the contractor that he will make his own assessment.
If the PM failed to respond within the timescales, the contractor notifies him. If the PM fails to respond within a further 2 weeks, the quotation is deemed to be accepted.
Timescales can be extended if the parties agree.

70
Q

If there is a discrepancy between the employer’s requirements and
contractor’s proposals which prevail?

A

The Contractor’s Proposals.

71
Q

What is the contractor’s design liability under JCT contracts?

A

The same as an independently employed architect with the duty to offer reasonable skill and care